_______________________________________________

 

                            ENGROSSED SENATE BILL 6441

                  _______________________________________________

 

State of Washington              52nd Legislature             1992 Regular Session

 

By Senators McMullen and Matson

 

Read first time 01/30/92.  Referred to Committee on Commerce & Labor.Establishing construction lien rights.


     AN ACT Relating to construction liens; amending RCW 60.04.011, 60.04.031, 60.04.041, 60.04.051, 60.04.081, 60.04.091, 60.04.141, 60.04.151, 60.04.161, 60.04.171, 60.04.181, and 60.04.221; adding a new section to chapter 60.04 RCW; and providing an effective date.

 

BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF WASHINGTON:

 

     Sec. 1.  RCW 60.04.011 and 1991 c 281 s 1 are each amended to read as follows:

     Unless the context requires otherwise, the definitions in this section apply throughout this chapter.

     (1) "Construction agent" means any registered or licensed contractor, registered or licensed subcontractor, architect, engineer, or other person having charge of any improvement to real property, who shall be deemed the agent of the owner for the limited purpose of establishing the lien created by this chapter.

     (2) "Contract price" means the amount agreed upon by the contracting parties, or if no amount is agreed upon, then the customary and reasonable charge therefor.

     (3) "Draws" means periodic disbursements of interim or construction financing by a lender.

     (4) "Furnishing labor, professional services, materials, or equipment" means the performance of any labor or professional services, the contribution owed to any employee benefit plan on account of any labor, the provision of any supplies or materials, and the renting, leasing, or otherwise supplying of equipment for the improvement of real property.

     (5) "Improvement" means:  (a) Constructing, altering, repairing, remodeling, demolishing, clearing, grading, or filling in, of, to, or upon any real property or street or road in front of or adjoining the same; (b) planting of trees, vines, shrubs, plants, hedges, or lawns, or providing other landscaping materials on any real property; and (c) providing professional services upon real property or in preparation for or in conjunction with the intended activities in (a) or (b) of this subsection.

     (6) "Interim or construction financing" means that portion of money secured by a mortgage, deed of trust, or other encumbrance to finance improvement of, or to real property, but does not include:

     (a) Funds to acquire real property;

     (b) Funds to pay interest, insurance premiums, lease deposits, taxes, assessments, or prior encumbrances;

     (c) Funds to pay loan, commitment, title, legal, closing, recording, or appraisal fees;

     (d) Funds to pay other customary fees, which pursuant to agreement with the owner or borrower are to be paid by the lender from time to time;

     (e) Funds to acquire personal property for which the potential lien claimant may not claim a lien pursuant to this chapter.

     (7) "Labor" means exertion of the powers of body or mind performed at the site for compensation.  "Labor" includes amounts due and owed to any employee benefit plan on account of such labor performed.

     (8) "Mortgagee" means a person who has a valid mortgage of record or deed of trust of record securing a loan.

     (9) (("Owner" means the record holder of any legal or beneficial title to the real property to be improved or developed.

     (10))) "Owner-occupied" means a single-family residence occupied by the owner as his or her principal residence.

     (((11))) (10) "Payment bond" means a surety bond issued by a surety licensed to issue surety bonds in the state of Washington that confers upon potential claimants the rights of third party beneficiaries.

     (((12))) (11) "Potential lien claimant" means any person or entity entitled to assert lien rights under this chapter who has otherwise complied with the provisions of this chapter and is registered or licensed if required to be licensed or registered by the provisions of the laws of the state of Washington.

     (((13))) (12) "Prime contractor" includes all contractors, general contractors, and specialty contractors, as defined by chapter 18.27 or 19.28 RCW, or who are otherwise required to be registered or licensed by law, who contract directly with a property owner or their common law agent to assume primary responsibility for the creation of an improvement to real property, and includes property owners or their common law agents who are contractors, general contractors, or specialty contractors as defined in chapter 18.27 or 19.28 RCW, or who are otherwise required to be registered or licensed by law, who offer to sell their property without occupying or using the structures, projects, developments, or improvements for more than one year.

     (((14))) (13) "Professional services" means surveying, establishing or marking the boundaries of, preparing maps, plans, or specifications for, or inspecting, testing, or otherwise performing any other architectural or engineering services for the improvement of real property.

     (((15))) (14) "Real property lender" means a bank, savings bank, savings and loan association, credit union, mortgage company, or other corporation, association, partnership, trust, or individual that makes loans secured by real property located in the state of Washington.

     (((16))) (15) "Site" means the real property which is or is to be improved.

     (((17))) (16) "Subcontractor" means a general contractor or specialty contractor as defined by chapter 18.27 or 19.28 RCW, or who is otherwise required to be registered or licensed by law, who contracts for the improvement of real property with someone other than the owner of the property or their common law agent.

 

     Sec. 2.  RCW 60.04.031 and 1991 c 281 s 3 are each amended to read as follows:

     (1) Except as otherwise provided in this section, every person furnishing professional services, materials, or equipment for the improvement of real property shall give the owner or reputed owner notice in writing of the right to claim a lien.  If the prime contractor is in compliance with the requirements of RCW 19.27.095, 60.04.230, and 60.04.261, this notice shall also be given to the prime contractor as described in this subsection unless the potential lien claimant has contracted directly with the prime contractor.  The notice may be given at any time but only protects the right to claim a lien for professional services, materials, or equipment supplied after the date which is sixty days before:

     (a) Mailing the notice by certified or registered mail to the owner or reputed owner; or

     (b) Delivering or serving the notice personally upon the owner or reputed owner and obtaining evidence of ((service)) delivery in the form of a receipt or other acknowledgement signed by the owner or reputed owner or an affidavit of service.

     In the case of new construction of a single-family residence, the notice of a right to claim a lien may be given at any time but only protects the right to claim a lien for professional services, materials, or equipment supplied after a date which is ten days before the notice is mailed or served as described in this subsection.

     (2) Notices of a right to claim a lien shall not be required of:

     (a) Persons who contract directly with the owner or the owner's common law agent;

     (b) Laborers whose claim of lien is based solely on performing labor; or

     (c) Subcontractors who contract for the improvement of real property directly with the prime contractor, except as provided in subsection (3)(b) of this section.

     (3) Persons who furnish professional services, materials, or equipment in connection with the repair, alteration, or remodel of an existing owner-occupied single-family residence or appurtenant garage:

     (a) Who contract directly with the owner-occupier or their common law agent shall not be required to send a written notice of the right to claim a lien and shall have a lien for the full amount due under their contract, as provided in RCW 60.04.021; or

     (b) Who do not contract directly with the owner-occupier or their common law agent shall give notice of the right to claim a lien to the owner-occupier.  Liens ((claims by)) of persons furnishing professional services, materials, or equipment who do not contract directly with the owner-occupier or their common law agent may only be satisfied from amounts not yet paid to the prime contractor by the owner at the time the notice described in this section is received, regardless of whether amounts not yet paid to the prime contractor are due.  For the purposes of this section "received" means actual notice by personal service, or registered or certified mail, or three days after mailing by first class mail, excluding Saturdays, Sundays, or legal holidays.

     (4) The notice of right to claim a lien described in subsection (1) of this section, shall include but not be limited to the following information and shall substantially be in the following form, using lower-case and upper-case ten-point type where appropriate.

 

                                  NOTICE TO OWNER

 

               IMPORTANT:  READ BOTH SIDES OF THIS NOTICE CAREFULLY.

 

                        PROTECT YOURSELF FROM PAYING TWICE

 

To:..............................                Date:......................

Re:...................(description of property:  Street address or general location.)

From:.......................................................

 

AT THE REQUEST OF: .................... (Name of person ((placing the order)) ordering the professional services, materials, or equipment)

 

THIS IS NOT A LIEN: This notice is sent to you to tell you who is providing professional services, materials, or equipment for the improvement of your property and to advise you of the rights of these persons and your responsibilities.  Also take note that laborers on your project may claim a lien without sending you a notice.

 

                  OWNER/OCCUPIER OF EXISTING RESIDENTIAL PROPERTY

 

Under Washington law, those who ((work on or provide materials)) furnish labor, professional services, materials, or equipment for the repair, remodel, or alteration of your owner-occupied principal residence and who are not paid, have a right to enforce their claim for payment against your property.  This claim is known as a construction lien.

 

The law limits the amount that a lien claimant can claim against your property.  Claims may only be made against that portion of the contract price you have not yet paid to your prime contractor as of the time ((you received)) this notice was personally served on you or five days after this notice was mailed to you.  Review the back of this notice for more information and ways to avoid lien claims.

 

                    COMMERCIAL AND/OR NEW RESIDENTIAL PROPERTY

 

We have or will be providing ((labor, materials,)) professional services, materials, or equipment for the improvement of your commercial or new residential project.  In the event you or your contractor fail to pay us, we may file a lien against your property.  A lien may be claimed for all ((materials, equipment, and)) professional services, materials, or equipment furnished after a date that is sixty days before this notice was personally served on you or mailed to you, unless the improvement to your property is the construction of a new single-family residence, then ten days before this notice was personally served on you or mailed to you.

 

     Sender: ................................................

 

     Address: ...............................................

 

     Telephone: .............................................

 

Brief description of professional services, materials, or equipment provided or to be provided: .......................................

 

                       IMPORTANT INFORMATION ON REVERSE SIDE

 

 

                     IMPORTANT INFORMATION FOR YOUR PROTECTION

 

This notice is sent to inform you that we have or will provide ((materials,)) professional services, materials, or equipment for the repair, remodel, or alteration of your property.  We expect to be paid by the person who ordered our services, but if we are not paid, we have the right to enforce our claim by filing a construction lien against your property.

 

LEARN more about the lien laws and the meaning of this notice by discussing them with your contractor, suppliers, Department of Labor and Industries, the firm sending you this notice, your lender, or your attorney.

 

COMMON METHODS TO AVOID CONSTRUCTION LIENS:  There are several methods available to protect your property from construction liens.  The following are two of the more commonly used methods.

 

DUAL PAYCHECKS (Joint Checks):  When paying your contractor for services or materials, you may make checks payable jointly to the contractor and the firms furnishing you this notice.

 

LIEN RELEASES:  You may require your contractor to provide lien releases signed by all the suppliers and subcontractors from whom you have received this notice.  If they cannot obtain lien releases because you have not paid them, you may use the dual payee check method to protect yourself.

 

YOU SHOULD TAKE ((WHATEVER)) APPROPRIATE STEPS ((YOU BELIEVE NECESSARY)) TO PROTECT YOUR PROPERTY FROM LIENS.

 

YOUR PRIME CONTRACTOR AND YOUR CONSTRUCTION LENDER ARE REQUIRED BY LAW TO GIVE YOU WRITTEN INFORMATION ABOUT LIEN CLAIMS.  IF YOU HAVE NOT RECEIVED IT, ASK THEM FOR IT.

 

                             * * * * * * * * * * * * *

 

     (5) Every potential lien claimant providing professional services where no improvement as defined in RCW 60.04.011(5) (a) or (b) has been commenced, and the professional services provided are not visible from an inspection of the real property ((shall)) may record in the real property records of the county where the property is located a notice which shall contain the professional service provider's name, address, telephone number, legal description of the property, the owner or reputed owner's name, and the general nature of the professional services provided.  If such notice is not recorded, the lien claimed shall be subordinate to the interest of any subsequent mortgagee and invalid as to the interest of any subsequent purchaser ((who)) if the mortgagee or purchaser acts in good faith and for a valuable consideration acquires an interest in the property prior to the commencement of an improvement as defined in RCW 60.04.011(5) (a) or (b) without notice of the professional services being provided.  The notice described in this subsection shall be substantially in the following form:

                    NOTICE OF FURNISHING PROFESSIONAL SERVICES

 

     That on the  (day)  day of  (month and year) ,  (name of provider)  began providing professional services upon or for the improvement of real property legally described as follows:

 

                                [Legal Description

                                   is mandatory]

 

     The general nature of the professional services provided is

..................................................................... .....................................................................

The owner or reputed owner of the real property is ..................

.....................................................................

 

                                           ............................

                                                     (Signature)

 

                                           ............................

                                                 (Name of Claimant)

 

                                           ............................

                                                  (Street Address)

 

                                           ............................

                                              (City, State, Zip Code)

 

                                           ............................

                                                   (Phone Number)

 

     (6) A lien authorized by this chapter shall not be enforced unless the lien claimant has complied with the applicable provisions of this section.

 

     NEW SECTION.  Sec. 3.  A new section is added to chapter 60.04 RCW to read as follows:

     Any act of coercion or attempted coercion, including a threat to withhold future contracts, by a contractor or developer to discourage a contractor, subcontractor, or material or equipment supplier from giving an owner the notice of right to claim a lien required by RCW 60.04.031, or from filing a lien claim under this chapter shall constitute an unfair or deceptive act or practice in trade or commerce and a violation of chapter 19.86 RCW.

 

     Sec. 4.  RCW 60.04.041 and 1991 c 281 s 4 are each amended to read as follows:

     A contractor or subcontractor required to be registered under chapter 18.27 RCW or licensed under chapter 19.28 RCW, or otherwise required to be registered or licensed by law, shall be deemed the construction agent of the owner for the purposes of establishing the lien created by this chapter only if so registered or licensed.  Persons dealing with contractors or subcontractors may rely, for the purposes of this section, upon a certificate of registration issued pursuant to chapter 18.27 RCW or license issued pursuant to chapter 19.28 RCW, or other certificate or license issued pursuant to law, covering the period when the labor, professional services, material, or equipment shall be furnished, and the lien rights shall not be lost by suspension or revocation of registration or license without their knowledge.  No lien rights described in this ((section)) chapter shall be lost or denied by virtue of the absence, suspension, or revocation of such registration or license with respect to any contractor or subcontractor not in immediate contractual privity with the lien claimant.

 

     Sec. 5.  RCW 60.04.051 and 1991 c 281 s 5 are each amended to read as follows:

     The lot, tract, or parcel of land which is improved is subject to a lien to the extent of the interest of the ((person for whom)) owner at whose instance, directly or through a common law or construction agent the labor, professional services, equipment, or materials were furnished, as the court deems appropriate for satisfaction of the lien.  If, for any reason, the title or interest in the land upon which the improvement is situated cannot be subjected to the lien, the court in order to satisfy the lien may order the sale and removal of the improvement from the land which is subject to the lien((, from the land)).

 

     Sec. 6.  RCW 60.04.081 and 1991 c 281 s 8 are each amended to read as follows:

     (1) Any owner of real property subject to a recorded ((notice of)) claim of lien under this chapter, or ((the)) contractor ((or)), subcontractor, lender, or lien claimant who believes the claim of lien to be frivolous and made without reasonable cause, or clearly excessive may apply by motion to the superior court for the county where the property, or some part thereof is located, for an order directing the lien claimant to appear before the court at a time no earlier than six nor later than fifteen days following the date of service of the application and order on the lien claimant, and show cause, if any he or she has, why the ((lien claim)) relief requested should not be ((dismissed, with prejudice)) granted.  The motion shall state the grounds upon which relief is asked, and shall be supported by the affidavit of the applicant or his or her attorney setting forth a concise statement of the facts upon which the motion is based.

     (2) The order shall clearly state that if the lien claimant fails to appear at the time and place noted the lien ((claim)) shall be ((dismissed)) released, with prejudice (([,])), and that the lien claimant shall be ordered to pay the costs requested by the applicant including reasonable attorneys' fees.

     (3) If no action to foreclose the lien claim has been filed, the clerk of the court shall assign a cause number to the application and obtain from the applicant a filing fee of thirty-five dollars.  If an action has been filed to foreclose the lien claim, the application shall be made a part of that action.

     (4) If, following a ((full)) hearing on the matter, the court determines that the lien ((claim)) is frivolous and made without reasonable cause, or clearly excessive, the court shall issue an order ((dismissing)) releasing the lien claim if frivolous and made without reasonable cause, or reducing the ((claim)) lien if clearly excessive, and awarding costs and reasonable attorneys' fees to the applicant to be paid by the lien claimant.  If the court determines that the ((claim of)) lien is not frivolous and was made with reasonable cause, and is not clearly excessive, the court shall issue ((and)) an order so stating and awarding costs and reasonable attorneys' fees to the lien claimant to be paid by the applicant.

     (5) Proceedings under this section shall not affect other rights and remedies available to the parties under this chapter or otherwise.

 

     Sec. 7.  RCW 60.04.091 and 1991 c 281 s 9 are each amended to read as follows:

     Every person claiming a lien under RCW 60.04.021 shall ((record)) file for recording, in the county where the subject property is located, a notice of claim of lien not later than ninety days after the person has ceased to furnish labor, professional services, materials, or equipment or the last date on which employee benefit contributions were due.  The notice of claim of lien:

     (1) Shall state in substance and effect:

     (a) The name, phone number, and address of the claimant;

     (b) The first and last date on which the labor, professional services, materials, or equipment was furnished or employee benefit contributions were due;

     (c) The name of the person indebted to the claimant;

     (d) The street address, legal description, or other description reasonably calculated to identify, for a person familiar with the area, the location of the real property to be charged with the lien;

     (e) The name of the owner or reputed owner of the property, if known, and, if not known, that fact shall be stated; and

     (f) The principal amount for which the lien is claimed.

     (2) Shall be signed by the claimant or some person authorized to act on his or her behalf who shall affirmatively state they have read the notice of claim of lien and believe the notice of claim of lien to be true and correct under penalty of perjury, and shall be acknowledged pursuant to chapter 64.08 RCW.  If the ((claim)) lien has been assigned, the name of the assignee shall be stated.  Where an action to foreclose the lien has been commenced such notice of claim of lien may be amended as pleadings may be by order of the court insofar as the interests of third parties are not adversely affected by such amendment.  A claim of lien substantially in the following form shall be sufficient:

 

                                   CLAIM OF LIEN

          ......, claimant, vs .., ((owner or reputed owner)) defendant:

 

((Notice is hereby given that on the ..... day of ..... (date of commencement of furnishing labor, professional services, materials,  or equipment and the last date contributions to any type of employee benefit plan became due), ..... at the request of .........., .......... commenced to (perform labor, furnish professional services,  materials, or equipment) upon .......... (here describe property subject to the lien) of which property the owner, or reputed owner, is .......... (or if the owner or reputed owner is not known, insert the word "unknown"), the (furnishing of labor, professional services, materials, or equipment) ceased on the ..... day of ..........;     that said (labor, professional services, material, or equipment)  was of the value of .......... dollars, for which the undersigned claims a lien upon the property herein described for the sum of .......... dollars.  (In case the claim has been assigned, add the words "and .......... is assignee of said claim", or claims, if several are united.))) Notice is hereby given that the person named below claims a lien pursuant to chapter 64.04 RCW.  In support of this lien the following information is submitted:

 

             1. NAME OF LIEN CLAIMANT: ..............................

                TELEPHONE NUMBER: ...................................

                ADDRESS: ............................................

 

 

     2. DATE ON WHICH THE CLAIMANT BEGAN TO PERFORM LABOR, PROVIDE PROFESSIONAL SERVICES, SUPPLY MATERIAL OR EQUIPMENT OR THE DATE ON WHICH EMPLOYEE BENEFIT CONTRIBUTIONS BECAME

     DUE: ..........................................................

 

     3. NAME OF PERSON INDEBTED TO THE CLAIMANT:

...............................................................

 

     4. DESCRIPTION OF THE PROPERTY AGAINST WHICH A LIEN IS CLAIMED (Street address, legal description or other information that will reasonably describe the property). ..................

...............................................................

...............................................................

...............................................................

 

     5. NAME OF THE OWNER OR REPUTED OWNER (If not known state "unknown"):....................................................

 

     6. THE LAST DATE ON WHICH LABOR WAS PERFORMED; PROFESSIONAL SERVICES WERE FURNISHED; CONTRIBUTIONS TO AN EMPLOYEE BENEFIT PLAN WERE DUE; OR MATERIAL, OR EQUIPMENT WAS FURNISHED:.....................................................

...............................................................

 

     7. IF THE CLAIMANT IS THE ASSIGNEE OF THIS CLAIM SO STATE HERE:..........................................................

...............................................................

 

                                                     ...................., Claimant

                                                     ..............................

                                                     ..............................

                                                      (Phone number, address, city,

                                                             and state of claimant)      

 

STATE OF WASHINGTON, COUNTY OF

..........,ss.

.........., being sworn, says:  I am the claimant (or attorney of the claimant, or administrator, representative, or agent of the trustees of an employee benefit plan) above named; I have read or heard the foregoing claim, read and know the contents thereof, and believe the same to be true and correct and that the claim of lien is not frivolous, is made with reasonable cause and is not clearly excessive under penalty of perjury.

 

                                                     ..............................

Subscribed and sworn to before me this ..... day of ........

                                                     ..............................

 

     The period provided for recording the ((notice)) claim of lien is a period of limitation and no action to foreclose a ((claim of)) lien shall be maintained unless the ((notice is recorded)) claim of lien is filed for recording within the ninety-day period stated.  The lien claimant shall give ((notice of)) a copy of the claim of lien to the owner or reputed owner by mailing it by certified or registered mail or by personal service within fourteen days of the time the claim of lien is ((recorded)) filed for recording.  Failure to do so results in a forfeiture of any right the claimant may have to attorneys' fees and costs against the owner under RCW 60.04.181.

 

     Sec. 8.  RCW 60.04.141 and 1991 c 281 s 14 are each amended to read as follows:

     No lien created by this chapter binds the property subject to the lien for a longer period than eight calendar months after the ((notice of)) claim of lien has been recorded unless an action is filed by the lien claimant within that time in the superior court in the county where the subject property is located to enforce the lien, and service is made upon the owner of the subject property within ninety days of the date of filing the action; or, if credit is given and the terms thereof are stated in the ((notice of)) claim of lien, then eight calendar months after the expiration of such credit; and in case the action is not prosecuted to judgment within two years after the commencement thereof, the court, in its discretion, may dismiss the action for want of prosecution, and the dismissal of the action or a judgment rendered thereon that no lien exists shall constitute a cancellation of the lien.  This is a period of limitation, which shall be tolled by the filing of any petition seeking protection under Title Eleven, United States Code by an owner of any property subject to the lien established by this chapter.

 

     Sec. 9.  RCW 60.04.151 and 1991 c 281 s 15 are each amended to read as follows:

     The lien claimant shall be entitled to recover upon the claim recorded the contract price after deducting all claims of other lien claimants to whom the claimant is liable, for furnishing labor, professional services, materials, or equipment; and in all cases where a ((notice of)) claim of lien shall be recorded under this chapter for labor, professional services, materials, or equipment supplied to any lien claimant, he or she shall defend any action brought thereupon at his or her own expense((; and)).  During the pendency of the action, the owner may withhold from the prime contractor the amount of money for which a claim is recorded by any subcontractor, supplier, or laborer((; and)).  In case of judgment against the owner or the owner's property, upon the lien, the owner shall be entitled to deduct from sums due to the prime contractor the principal amount of the judgment from any amount due or to become due from ((him or her)) the owner to the ((lien claimant)) prime contractor plus such costs, including interest and attorneys' fees, as the court deems just and equitable, and ((he or she)) the owner shall be entitled to recover back from the ((lien claimant)) prime contractor the amount for which ((the)) a lien ((is)) or liens are established in excess of any sum that may remain due from ((him or her)) the owner to the ((lien claimant)) prime contractor.

 

     Sec. 10.  RCW 60.04.161 and 1991 c 281 s 16 are each amended to read as follows:

     Any owner of real property subject to a recorded ((notice of)) claim of lien under this chapter, or ((the)) contractor ((or)), subcontractor, lender, or lien claimant who disputes the correctness or validity of the ((notice of)) claim of lien may record, either before or after the commencement of an action to enforce the lien, in the office of the county recorder or auditor in the county where the ((notice of)) claim of lien was recorded, a bond issued by a surety company authorized to issue surety bonds in the state.  The surety shall be listed in the latest federal department of the treasury list of surety companies acceptable on federal bonds, published in the Federal Register, as authorized to issue bonds on United States government projects with an underwriting limitation, including applicable reinsurance, equal to or greater than the amount of the bond to be recorded.  The bond shall contain a description of the ((notice of)) claim of lien and real property involved, and be in an amount equal to the greater of five thousand dollars or two times the amount of the lien claimed if it is ten thousand dollars or less, and in an amount equal to or greater than one and one-half times the amount of the lien if it is in excess of ten thousand dollars.  If the ((notice of)) claim of lien affects more than one parcel of real property and is segregated to each parcel, the bond may be segregated the same as in the ((notice of)) claim of lien.  A separate bond shall be required for each ((notice of)) claim of lien made by separate claimants.  However, a single bond may be used to guarantee payment of amounts claimed by more than one ((lien)) claim of lien by a single claimant so long as the amount of the bond meets the requirements of this section as applied to the aggregate sum of all claims by such claimant.  The condition of the bond shall be to guarantee payment of any judgment upon the lien in favor of the lien claimant entered in any action to recover the amount claimed in a ((notice of)) claim of lien, or on the claim asserted in the ((notice of)) claim of lien.  The effect of recording a bond shall be to release the real property described in the notice of claim of lien from the lien and any action brought to recover the amount claimed.  Unless otherwise prohibited by law, if no action is commenced to recover on a lien within the time specified in RCW 60.04.141, the surety shall be discharged from liability under the bond.  If an action is timely commenced, then on payment of any judgment entered in the action or on payment of the full amount of the bond to the holder of the judgment, whichever is less, the surety shall be discharged from liability under the bond.

     Nothing in this section shall in any way prohibit or limit the use of other methods, devised by the affected parties to secure the obligation underlying a claim of lien and to obtain a release of real property from a claim of lien.

 

     Sec. 11.  RCW 60.04.171 and 1991 c 281 s 17 are each amended to read as follows:

     The lien provided by this chapter, for which claims of lien have been recorded, may be foreclosed and enforced by a civil action in the court having jurisdiction in the manner prescribed for the judicial foreclosure of a mortgage.  The court shall have the power to order the sale of the property.  In any action brought to foreclose a lien, the owner shall be joined as a party.  The ((lien claims of all)) interest in the real property of any person((s)) who, prior to the commencement of the action, ((have legally)) has a recorded ((claims of lien against)) interest in the ((same)) property, or any part thereof, shall not be foreclosed or affected unless they are joined as a party.

     A person shall not begin an action to foreclose a lien upon any property while a prior action begun to foreclose another lien on the same property is pending, but if not made a party plaintiff or defendant to the prior action, he or she may apply to the court to be joined as a party thereto, and his or her lien may be foreclosed in the same action.  The filing of such application shall toll the running of the period of limitation established by RCW 60.04.141 until disposition of the application or other time set by the court.  The court shall grant the application for joinder unless to do so would create an undue delay or cause hardship which cannot be cured by the imposition of costs or other conditions as the court deems just.  If a lien foreclosure action is filed during the pendency of another such action, the court may, on its own motion or the motion of any party, consolidate actions upon such terms and conditions as the court deems just, unless to do so would create an undue delay or cause hardship which cannot be cured by the imposition of costs or other conditions.  If consolidation of actions is not permissible under this section, the lien foreclosure action filed during the pendency of another such action shall not be dismissed if the filing was the result of mistake, inadvertence, surprise, excusable neglect, or irregularity.  An action to foreclose a lien shall not be dismissed at the instance of a plaintiff therein to the prejudice of another party to the suit who claims a lien.

 

     Sec. 12.  RCW 60.04.181 and 1991 c 281 s 18 are each amended to read as follows:

     (1) In every case in which different construction liens are claimed against the same property, the court shall declare the rank of such lien or class of liens, which liens shall be in the following order:

     (a) Liens for the performance of labor;

     (b) Liens for contributions owed to employee benefit plans;

     (c) Liens for furnishing material, supplies, or equipment;

     (d) Liens for subcontractors, including but not limited to their labor and materials; and

     (e) Liens for prime contractors, or for professional services.

     (2) The proceeds of the sale of property must be applied to each lien or class of liens in order of its rank and, in an action brought to foreclose a lien, pro rata among each claimant in each separate priority class.  A personal judgment may be rendered against any party personally liable for any debt for which the lien is claimed.  If the lien is established, the judgment shall provide for the enforcement thereof upon the property liable as in the case of foreclosure of judgment liens.  The amount realized by such enforcement of the lien shall be credited upon the proper personal judgment.  The deficiency, if any, remaining unsatisfied, shall stand as a personal judgment, and may be collected by execution against any party liable therefor.

     (3) The court may allow the prevailing party in the action, whether plaintiff or defendant, as part of the costs of the action, the moneys paid for recording the ((notice of)) claim of lien, costs of title report, bond costs, and attorneys' fees and necessary expenses incurred by the attorney in the superior court, court of appeals, supreme court, or arbitration, as the court or arbitrator deems reasonable.  Such costs shall have the priority of the class of lien to which they are related, as established by subsection (1) of this section.

     (4) Real property against which a lien under this chapter is enforced may be ordered sold by the court and the proceeds deposited into the registry of the clerk of the court, pending further determination respecting distribution of the proceeds of the sale.

 

     Sec. 13.  RCW 60.04.221 and 1991 c 281 s 22 are each amended to read as follows:

     Any lender providing interim or construction financing where there is not a payment bond of at least fifty percent of the amount of construction financing shall observe the following procedures and the rights and liabilities of the lender and potential lien claimant shall be affected as follows:

     (1) Any potential lien claimant who has not received a payment within five days after the date required by their contract, invoice, employee benefit plan agreement, or purchase order may within thirty-five days of the date required for payment of the contract, invoice, employee benefit plan agreement, or purchase order, ((file)) give a notice as provided in subsections (2) and (3) of this section of the sums due and to become due, for which a potential lien claimant may claim a lien under this chapter.

     (2) The notice shall be signed by the potential lien claimant or some person authorized to act on his or her behalf ((who shall affirmatively state under penalty of perjury, they have read the notice and believe it to be true and correct)).

     (3) The notice shall be ((filed)) given in writing ((with)) to the lender at the office administering the interim or construction financing, with a copy ((furnished)) given to the owner and appropriate prime contractor.  The notice shall be given by:

     (a) Mailing the notice by certified or registered mail to the lender, owner, and appropriate prime contractor;

     (b) Delivering or serving the notice personally and obtaining evidence of delivery in the form of a receipt or other acknowledgment signed by the lender, owner, and appropriate prime contractor, or an affidavit of service;

     (c) Any combination of (a) and (b) of this subsection.

     (4) The notice shall state in substance and effect as follows:

     (a) The person, firm, trustee, or corporation filing the notice is entitled to receive contributions to any type of employee benefit plan or has furnished labor, professional services, materials, or equipment for which a ((right of)) lien is given by this chapter.

     (b) The name of the prime contractor, common law agent, or construction agent ordering the same.

     (c) A common or street address of the real property being improved or the legal description of the real property.

     (d) The name, business address, and telephone number of the lien claimant.

     The notice to the lender may contain additional information but shall be in substantially the following form:

 

                          NOTICE TO REAL PROPERTY LENDER

                          (Authorized by RCW ..........)

 

TO:  .............................................................

                         (Name of Lender)

.............................................................

                         (Administrative Office-Street Address)

.............................................................

                         (City) (State) (Zip)

AND TO: .............................................................

                         (Owner)

AND TO: .............................................................

             (Prime Contractor-If Different Than Owner)

.............................................................

(Name of Laborer, Professional, Materials, or Equipment Supplier)

whose business address is ........................., did at the property located at ..........................

(Check appropriate box) ( ) perform labor ( ) furnish professional services ( ) provide materials ( ) supply equipment as follows:

................................................................

................................................................

................................................................

which was ordered by ...........................................,

                                                 (Name of Person)

whose address was stated to be..................................

................................................................

 

     The amount owing to the undersigned according to contract or purchase order for labor, supplies, or equipment (as above mentioned) is the sum of ......................... Dollars

 ($ .......... ).  Said sums became due and owing as of

 ...............................................................

                                           (State Date)

 ..........................................., ..................

 

     You are hereby required to withhold from any future draws on existing construction financing which has been made on the subject property (to the extent there remain undisbursed funds) the sum of ......................... Dollars

 ($ .......... ).

 

                                     IMPORTANT

 

Failure to comply with the requirements of this notice may subject the lender to a whole or partial compromise of any priority lien interest it may have pursuant to RCW 60.04.226.

 

                                     DATE:  ..............

                                                                  

                                                 By: ...................

                                                 Its: ..................

 

     (((4))) (5) After the receipt of the notice, the lender shall withhold from the next and subsequent draws the amount claimed to be due as stated in the notice.  Alternatively, the lender may obtain from the prime contractor or borrower a payment bond for the benefit of the potential lien claimant in an amount sufficient to cover the amount stated in the potential lien claimant's notice.  The lender shall be obligated to withhold amounts only to the extent that sufficient interim or construction financing funds remain undisbursed as of the date the lender receives the notice.

     (((5))) (6) Sums so withheld shall not be disbursed by the lender, except by the written agreement of the potential lien claimant, owner, and prime contractor in such form as may be prescribed by the lender, or the order of a court of competent jurisdiction.

     (((6))) (7) In the event a lender fails to abide by the provisions of subsections (4) and (5) of this section, then the mortgage, deed of trust, or other encumbrance securing the lender ((will)) shall be subordinated to the lien of the potential lien claimant to the extent of the interim or construction financing wrongfully disbursed, but in no event more than the amount stated in the notice plus costs as fixed by the court, including reasonable attorneys' fees.

     (((7))) (8) Any potential lien claimant shall be liable for any loss, cost, or expense, including reasonable attorneys' fees and statutory costs, to a party injured thereby arising out of any unjust, excessive, or premature notice filed under purported authority of this section.  "Notice" as used in this subsection does not include notice given by a potential lien claimant of the right to claim liens under this chapter where no actual claim is made.

     (((8))) (9)(a) Any owner of real property subject to a notice to real property lender under this section, or the contractor or subcontractor, or lien claimants who believe((s)) the claim that underlies the notice is frivolous and made without reasonable cause, or is clearly excessive may apply by motion to the superior court for the county where the property, or some part thereof is located, for an order commanding the potential lien claimant who issued the notice to the real property lender to appear before the court at a time no earlier than six nor later than fifteen days from the date of service of the application and order on the potential lien claimant, and show cause, if any he or she has, why the notice to real property lender should not be declared void.  The motion shall state the grounds upon which relief is asked and shall be supported by the affidavit of the applicant or his or her attorney setting forth a concise statement of the facts upon which the motion is based.

     (b) The order shall clearly state that if the potential lien claimant fails to appear at the time and place noted, the notice to lender shall be declared void and that the potential lien claimant issuing the notice shall be ordered to pay the costs requested by the applicant including reasonable attorneys' fees.

     (c) The clerk of the court shall assign a cause number to the application and obtain from the applicant a filing fee of thirty-five dollars.

     (d) If, following a ((full)) hearing on the matter, the court determines that the claim upon which the notice to real property lender is based is frivolous and made without reasonable cause, or clearly excessive, the court shall issue an order declaring the notice to real property lender void if frivolous, made without reasonable cause, or reducing the amount stated in the notice if clearly excessive, and awarding costs and reasonable attorneys' fees to the applicant to be paid by the person who issued the notice.  If the court determines that the claim underlying the notice to real property lender is not frivolous and was made with reasonable cause, and is not clearly excessive, the court shall issue an order so stating and awarding costs and reasonable attorneys' fees to the issuer of the notice to be paid by the applicant.

     (e) Proceedings under this subsection shall not affect other rights and remedies available to the parties under this chapter or otherwise.

 

     NEW SECTION.  Sec. 14.     This act shall take effect April 1, 1992.