READ FIRST TIME 02/28/07.   

     AN ACT Relating to alternative public works; amending RCW 39.10.010, 39.10.020, 39.10.800, 39.10.810, 39.10.080, 39.10.070, 39.10.130, 39.10.120, 60.28.011, and 70.150.070; reenacting and amending RCW 39.10.051 and 39.10.061; adding new sections to chapter 43.131 RCW; adding new sections to chapter 39.10 RCW; recodifying RCW 39.10.010, 39.10.020, 39.10.800, 39.10.810, 39.10.051, 39.10.080, 39.10.070, 39.10.061, 39.10.130, 39.10.100, 39.10.090, 39.10.120, 39.10.900, and 39.10.901; repealing RCW 39.10.902, 39.10.030, 39.10.040, 39.10.063, 39.10.065, 39.10.067, 39.10.068, 39.10.115, and 39.10.117; providing effective dates; and declaring an emergency.

BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF WASHINGTON:

Sec. 1   RCW 39.10.010 and 1994 c 132 s 1 are each amended to read as follows:
     The legislature finds that the traditional process of awarding public works contracts in lump sum to the lowest responsible bidder is a fair and objective method of selecting a contractor. However, under certain circumstances, alternative public works contracting procedures may best serve the public interest if such procedures are implemented in an open and fair process based on objective and equitable criteria. The purpose of this chapter is to authorize the use of certain supplemental alternative public works contracting procedures ((by state agencies and large municipalities under limited circumstances)), to prescribe appropriate requirements to ensure that such contracting procedures serve the public interest, and to establish a process for evaluation of such contracting procedures.

Sec. 101   RCW 39.10.020 and 2005 c 469 s 3 are each amended to read as follows:
     Unless the context clearly requires otherwise, the definitions in this section apply throughout this chapter.
     (1) "Alternative public works contracting procedure" means the design-build ((and the)), general contractor/construction manager, and job order contracting procedures authorized in RCW 39.10.051 ((and)), 39.10.061, and 39.10.130 (as recodified by this act), respectively. ((Public bodies eligible to enter into agreements with service providers for the furnishing of services in connection with water pollution control facilities under the authority of chapter 70.150 RCW may elect to use either RCW 39.10.051 and 39.10.061 or chapter 70.150 RCW as their method of procurement for such services.))
     (2) (("Public body" means the state department of general administration; the University of Washington; Washington State University; every city with a population greater than seventy thousand and any public authority chartered by such city under RCW 35.21.730 through 35.21.755 and specifically authorized as provided in RCW 39.10.120(4); every county with a population greater than four hundred fifty thousand; every port district with total revenues greater than fifteen million dollars per year; every public hospital district with total revenues greater than fifteen million dollars per year utilizing the design-build procedure authorized by RCW 39.10.051 and every public hospital district, regardless of total revenues, proposing projects that are considered and approved by the public hospital district project review board under RCW 39.10.117; every public utility district with revenues from energy sales greater than twenty-three million dollars per year; those school districts proposing projects that are considered and approved by the school district project review board under RCW 39.10.115; and the state ferry system.)) "Board" means the capital projects advisory review board.
     (3) (("Public works project" means any work for a public body within the definition of the term public work in RCW 39.04.010.)) "Committee" means the project review committee.
     (4) "Design-build procedure" means a contract between a public body and another party in which the party agrees to both design and build the facility, portion of the facility, or other item specified in the contract.
     (5) "Total contract cost" means the fixed amount for the detailed specified general conditions work, the negotiated maximum allowable construction cost, and the percent fee on the negotiated maximum allowable construction cost.
     (6) "General contractor/construction manager" means a firm with which a public body has selected and negotiated a maximum allowable construction cost to provide services during the design phase and to act as construction manager and general contractor during the construction phase.
     (7) "Job order contract" means a contract ((between a public body or any school district and a registered or licensed contractor)) in which the contractor agrees to a fixed period, indefinite quantity delivery order contract which provides for the use of negotiated, definitive work orders for public works as defined in RCW 39.04.010.
     (((5))) (8) "Job order contractor" means a registered or licensed contractor awarded a job order contract.
     (((6))) (9) "Maximum allowable construction cost" means the maximum cost of the work to construct the project including a percentage for risk contingency, negotiated support services, and approved change orders.
     (10) "Negotiated support services" means items a general contractor would normally manage or perform on a construction project including, but not limited to surveying, hoisting, safety enforcement, provision of toilet facilities, temporary heat, cleanup, and trash removal.
     (11) "Percent fee" means the percentage amount to be earned by the general contractor/construction manager as overhead and profit.
     (12) "Public body" means any general or special purpose government, including but not limited to state agencies, institutions of higher education, counties, cities, towns, ports, school districts, and special purpose districts.
     (13) "Certified public body" means a public body certified to use design-build or general contractor/construction manager contracting procedures, or both, under section 107 of this act.
     (14) "Public works project" means any work for a public body within the definition of "public work" in RCW 39.04.010.
     (15) "Total project cost" means the cost of the project less financing and land acquisition costs.
     (16) "Unit price book" means a book containing specific prices, based on generally accepted industry standards and information, where available, for various items of work to be performed by the job order contractor. The prices may include: All the costs of materials; labor; equipment; overhead, including bonding costs; and profit for performing the items of work. The unit prices for labor must be at the rates in effect at the time the individual work order is issued.
     (((7))) (17) "Work order" means an order issued for a definite scope of work to be performed pursuant to a job order contract.

Sec. 102   RCW 39.10.800 and 2005 c 377 s 1 are each amended to read as follows:
     (1) The ((capital projects advisory review)) board is created in the department of general administration to provide an evaluation of public capital projects construction processes, including the impact of contracting methods on project outcomes, and to advise the legislature on policies related to ((alternative)) public works delivery methods.
     (2)(a) The ((capital projects advisory review)) board shall consist of the following members appointed by the governor: ((One)) Two representatives from construction general contracting; one representative from the ((design industries)) architectural profession; one representative from the engineering profession; two representatives from construction specialty subcontracting; ((one)) two representatives from ((a)) construction trades labor organizations; one representative from the office of minority and women's business enterprises; one representative from a higher education institution; one representative from the department of general administration; two representatives from private industry; and one representative of a domestic insurer authorized to write surety bonds for contractors in Washington state. All appointed members must be ((actively engaged in or authorized to use alternative)) knowledgeable about public works contracting procedures.
     (b) ((Two)) Three members shall be ((at-large)) positions representing different local public owners((. The two at-large positions shall serve on a rotating basis to be determined and appointed)), selected by the association of Washington cities, the Washington state association of counties, and the Washington public ports association, respectively.
     (c) One member shall be a ((member of)) representative from the public hospital districts ((project review board)), selected by ((that board, who shall be nonvoting)) the association of Washington public hospital districts.
     (d) One member shall be a ((member of the)) representative from school districts ((project review board)), selected by ((that board, who shall be nonvoting)) the Washington state school directors' association.
     (e) The ((advisory review)) board shall include two members of the house of representatives, one from each major caucus, appointed by the speaker of the house of representatives, and two members of the senate, one from each major caucus, appointed by the president of the senate. Legislative members are nonvoting.
     (3) Members selected under subsection (2)(a) of this section shall serve for terms of four years, with the terms expiring on June 30th on the fourth year of the term. ((However, in the case of the initial members, four members shall serve four-year terms, four members shall serve three-year terms, and three members shall serve a two-year term, with each of the terms expiring on June 30th of the applicable year. Appointees may be reappointed to serve more than one term.))
     (4) The ((capital projects advisory review)) board chair is selected from among the appointed members by the majority vote of the voting members.
     (5) Legislative members of the ((capital projects advisory review)) board shall be reimbursed for travel expenses in accordance with RCW 44.04.120. Nonlegislative members of the ((capital projects advisory review)) board, ((including any subcommittee members, except those representing an employer or organization,)) project review committee members, and subcommittee chairs shall be reimbursed for travel expenses as provided in RCW 43.03.050 and 43.03.060.
     (6) If a vacancy occurs of the appointive members of the board, the governor shall fill the vacancy for the unexpired term. Members of the board may be removed for malfeasance or misfeasance in office, upon specific written charges by the governor, under chapter 34.05 RCW.
     (7) The ((capital projects advisory review)) board shall ((convene as soon as practical after July 1, 2005, and may)) meet as often as necessary ((thereafter)).
     (8) ((Capital projects advisory review)) Board members are expected to consistently attend ((review)) board meetings. The chair of the ((capital projects advisory review)) board may ask the governor to remove any member who misses more than two meetings in any calendar year without cause.
     (9) The department of general administration shall provide staff support as may be required for the proper discharge of the function of the ((capital projects advisory review)) board.
     (10) The ((capital projects advisory review)) board may establish subcommittees as it desires and may invite nonmembers of the ((capital projects advisory review)) board to serve as committee members.
     (11) The board shall encourage participation from persons and entities not represented on the ((capital projects advisory review)) board.

Sec. 103   RCW 39.10.810 and 2005 c 377 s 2 are each amended to read as follows:
     The ((capital projects advisory review)) board has the following powers and duties:
     (1) ((Develop and recommend to the legislature criteria that may be used to determine effective and feasible use of alternative contracting procedures;
     (2) Develop and recommend to the legislature qualification standards for general contractors bidding on alternative public works projects;
     (3))) Develop and recommend to the legislature policies to further enhance the quality, efficiency, and accountability of capital construction projects through the use of traditional and alternative delivery methods in Washington, and make recommendations regarding expansion, continuation, elimination, or modification of the alternative public works contracting methods;
     (((4))) (2) Evaluate the use of existing contracting procedures and potential future use of other alternative contracting procedures including competitive negotiation contracts;
     (3) Appoint members of the committee; and
     (4) Develop and administer questionnaires designed to provide quantitative and qualitative data on alternative public works contracting procedures on which evaluations are based.

NEW SECTION.  Sec. 104   PROJECT REVIEW COMMITTEE--CREATED. (1) The board shall establish a project review committee to review and approve public works projects using the design-build and general contractor/construction manager contracting procedures authorized in RCW 39.10.051 and 39.10.061 (as recodified by this act) and to certify public bodies as provided in section 107 of this act.
     (2) The board shall, by a majority vote of the board, appoint persons to the committee who are knowledgeable in the use of the design-build and general contractor/construction manager contracting procedures. Appointments must represent a balance among the industries and public owners on the board listed in RCW 39.10.800 (as recodified by this act).
     (a) When making initial appointments to the committee, the board shall consider for appointment former members of the school district project review board and the public hospital district project review board.
     (b) Each member of the committee shall be appointed for a term of three years. However, for initial appointments, the board shall stagger the appointment of committee members so that the first members are appointed to serve terms of one, two, or three years from the date of appointment. Appointees may be reappointed to serve more than one term.
     (c) The committee shall, by a majority vote, elect a chair and vice-chair for the committee.
     (d) The committee chair may select a person or persons on a temporary basis as a nonvoting member if project specific expertise is needed to assist in a review.
     (3) The chair of the committee, in consultation with the vice-chair, may appoint one or more panels of at least six committee members to carry out the duties of the committee. Each panel shall have balanced representation of the private and public sector representatives serving on the committee.
     (4) Any member of the committee directly or indirectly affiliated with a submittal before the committee must recuse himself or herself from the committee consideration of that submittal.
     (5) Any person who sits on the committee or panel is not precluded from subsequently bidding on or participating in projects that have been reviewed by the committee.
     (6) The committee shall meet as often as necessary to ensure that certification and approvals are completed in a timely manner.

NEW SECTION.  Sec. 105   PROJECT REVIEW COMMITTEE DUTIES. The committee shall:
     (1) Certify, or recertify, public bodies for a period of three years to use the design-build or general contractor/construction manager, or both, contracting procedures for projects with a total project cost of ten million dollars or more;
     (2) Review and approve the use of the design-build or general contractor/construction manager contracting procedures on a project by project basis for public bodies that are not certified under section 107 of this act; and
     (3) Review and approve the use of the general contractor/construction manager contracting procedure by certified public bodies for projects with a total project cost under ten million dollars.

NEW SECTION.  Sec. 106   PROJECT REVIEW COMMITTEE MEETINGS--OPEN AND PUBLIC. (1) The committee shall hold regular public meetings to carry out its duties as described in section 105 of this act. Committee meetings are subject to chapter 42.30 RCW.
     (2) The committee shall publish notice of its public meetings at least twenty days before the meeting in a legal newspaper circulated in the area where the public body seeking certification is located, or where each of the proposed projects under consideration will be constructed. All meeting notices must be posted on the committee's web site.
     (3) The meeting notice must identify the public body that is seeking certification or project approval, and where applicable, a description of projects to be considered at the meeting. The notice must indicate when, where, and how the public may present comments regarding the committee's certification of a public body or approval of a project. Information submitted by a public body to be reviewed at the meeting shall be available on the committee's web site at the time the notice is published.
     (4) The committee must allow for public comment on the appropriateness of certification of a public body or on the appropriateness of the use of the proposed contracting procedure and the qualifications of a public body to use the contracting procedure. The committee shall receive and record both written and oral comments at the public hearing.

NEW SECTION.  Sec. 107   PROJECT REVIEW COMMITTEE--CERTIFICATION OF PUBLIC BODIES. (1) A public body may apply for certification to use the design-build or general contractor/construction manager contracting procedure, or both. Once certified, a public body may use the contracting procedure for which it is certified on individual projects with a total project cost over ten million dollars without seeking committee approval. The certification period is three years. A public body seeking certification must submit to the committee an application in a format and manner as prescribed by the committee. The application must include a description of the public body's qualifications, its capital plan during the certification period, and its intended use of alternative contracting procedures.
     (2) To certify a public body, the committee shall determine that the public body:
     (a) Has the necessary experience and qualifications to determine which projects are appropriate for using alternative contracting procedures;
     (b) Has the necessary experience and qualifications to carry out the alternative contracting procedure including, but not limited to: (i) Project delivery knowledge and experience; (ii) personnel with appropriate construction experience; (iii) a management plan and rationale for its alternative public works projects; (iv) demonstrated success in managing public works projects; (v) demonstrated success in managing at least one general contractor/construction manager or design-build project within the previous five years; (vi) the ability to properly manage its capital facilities plan including, but not limited to, appropriate project planning and budgeting experience; and (vii) the ability to meet requirements of this chapter; and
     (c) Has resolved any audit findings on previous public works projects in a manner satisfactory to the committee.
     (3) The committee shall, if practicable, make its determination at the public meeting during which an application for certification is reviewed. Public comments must be considered before a determination is made. Within ten business days of the public meeting, the committee shall provide a written determination to the public body, and make its determination available to the public on the committee's web site.
     (4) The committee may revoke any public body's certification upon a finding, after a public hearing, that its use of design-build or general contractor/construction manager contracting procedures no longer serves the public interest.
     (5) The committee may renew the certification of a public body for one additional three-year period. The public body must submit an application for recertification at least three months before the initial certification expires. The application shall include updated information on the public body's capital plan for the next three years, its intended use of the procedures, and any other information requested by the committee. The committee must review the application for recertification at a meeting held before expiration of the applicant's initial certification period. A public body must reapply for certification under the process described in subsection (1) of this section once the period of recertification expires.
     (6) Certified public bodies must submit project data information as required in RCW 39.10.070 (as recodified by this act) and section 302 of this act.

NEW SECTION.  Sec. 108   PROJECT REVIEW COMMITTEE--PROJECT APPROVAL PROCESS. (1) A public body not certified under section 107 of this act must apply for approval from the committee to use the design-build or general contractor/construction manager contracting procedure on a project. A public body seeking approval must submit to the committee an application in a format and manner as prescribed by the committee. The application must include a description of the public body's qualifications, a description of the project, and its intended use of alternative contracting procedures.
     (2) To approve a proposed project, the committee shall determine that:
     (a) The alternative contracting procedure will provide a substantial fiscal benefit or the use of the traditional method of awarding contracts in lump sum to the low responsive bidder is not practical for meeting desired quality standards or delivery schedules;
     (b) The proposed project meets the requirements for using the alternative contracting procedure as described in section 201 or 301 of this act;
     (c) The public body has the necessary experience or qualified team to carry out the alternative contracting procedure including, but not limited to: (i) Project delivery knowledge and experience; (ii) sufficient personnel with construction experience to administer the contract; (iii) a written management plan that shows clear and logical lines of authority; (iv) the necessary and appropriate funding and time to properly manage the job and complete the project; (v) continuity of project management team, including personnel with experience managing projects of similar scope and size to the project being proposed; and (vi) necessary and appropriate construction budget;
     (d) For design-build projects, construction personnel independent of the design-build team are knowledgeable in the design-build process and are able to oversee and administer the contract; and
     (e) The public body has resolved any audit findings related to previous public works projects in a manner satisfactory to the committee.
     (3) The committee shall, if practicable, make its determination at the public meeting during which a submittal is reviewed. Public comments must be considered before a determination is made.
     (4) Within ten business days after the public meeting, the committee shall provide a written determination to the public body, and make its determination available to the public on the committee's web site. If the committee fails to make a written determination within ten business days of the public meeting, the request of the public body to use the alternative contracting procedure on the requested project shall be deemed approved.
     (5) The requirements of subsection (1) of this section also apply to certified public bodies seeking to use the general contractor/construction manager contracting procedure on projects with a total project cost of less than ten million dollars.
     (6) Failure of the committee to meet within sixty calendar days of a public body's application to use an alternative contracting procedure on a project shall be deemed an approval of the application.

NEW SECTION.  Sec. 109   APPEAL PROCESS. Final determinations by the committee may be appealed to the board within seven days by the public body or by an interested party. A written notice of an appeal must be provided to the committee and, as applicable, to the public body. The board shall resolve an appeal within forty-five days of receipt of the appeal and shall send a written determination of its decision to the party making the appeal and to the appropriate public body, as applicable. The public body shall comply with the determination of the board.

Sec. 201   RCW 39.10.051 and 2003 c 352 s 2 and 2003 c 300 s 4 are each reenacted and amended to read as follows:
     (1) ((Notwithstanding any other provision of law, and after complying with RCW 39.10.030, the following public bodies may utilize the design-build procedure of public works contracting for public works projects authorized under this section: The state department of general administration; the state ferry system; the University of Washington; Washington State University; every city with a population greater than seventy thousand and any public authority chartered by such city under RCW 35.21.730 through 35.21.755 and specifically authorized as provided in RCW 39.10.120(4); every county with a population greater than four hundred fifty thousand; every public utility district with revenues from energy sales greater than twenty-three million dollars per year; every public hospital district with total revenues greater than fifteen million dollars per year; and every port district with total revenues greater than fifteen million dollars per year. The authority granted to port districts in this section is in addition to and does not affect existing contracting authority under RCW 53.08.120 and 53.08.130. For the purposes of this section, "design-build procedure" means a contract between a public body and another party in which the party agrees to both design and build the facility, portion of the facility, or other item specified in the contract.
     (2) Public bodies authorized under this section)) Subject to the process in section 107 or 108 of this act, public bodies may utilize the design-build procedure for public works projects ((valued)) in which the total project cost is over ten million dollars and where:
     (a) The design and construction activities ((or)), technologies, or schedule to be used are highly specialized and a design-build approach is critical in developing the construction methodology or implementing the proposed technology; or
     (b) The project design is repetitive in nature and is an incidental part of the installation or construction; or
     (c) Regular interaction with and feedback from facilities users and operators during design is not critical to an effective facility design.
     (2) Subject to the process in section 107 or 108 of this act, public bodies may use the design-build procedure for parking garages, regardless of cost.
     (3) ((Public bodies authorized under this section may also use)) The design-build procedure also may be used for the ((following projects that meet the criteria in subsection (2)(b) and (c) of this section:
     (a) The)) construction or erection of preengineered metal buildings or prefabricated modular buildings, regardless of cost((; or
     (b) The construction of new student housing projects valued over five million dollars.
     (4) Contracts for design-build services shall be awarded through a competitive process utilizing public solicitation of proposals for design-build services. The public body shall publish at least once in a legal newspaper of general circulation published in or as near as possible to that part of the county in which the public work will be done, a notice of its request for proposals for design-build services and the availability and location of the request for proposal documents. The request for proposal documents shall include:
     (a) A detailed description of the project including programmatic, performance, and technical requirements and specifications, functional and operational elements, minimum and maximum net and gross areas of any building, and, at the discretion of the public body, preliminary engineering and architectural drawings;
     (b) The reasons for using the design-build procedure;
     (c) A description of the qualifications to be required of the proposer including, but not limited to, submission of the proposer's accident prevention program;
     (d) A description of the process the public body will use to evaluate qualifications and proposals, including evaluation factors and the relative weight of factors. Evaluation factors shall include, but not be limited to: Proposal price; ability of professional personnel; past performance on similar projects; ability to meet time and budget requirements; ability to provide a performance and payment bond for the project; recent, current, and projected work loads of the firm; location; and the concept of the proposal;
     (e) The form of the contract to be awarded;
     (f) The amount to be paid to finalists submitting best and final proposals who are not awarded a design-build contract; and
     (g) Other information relevant to the project.
     (5) The public body shall establish a committee to evaluate the proposals based on the factors, weighting, and process identified in the request for proposals. Based on its evaluation, the public body shall select not fewer than three nor more than five finalists to submit best and final proposals. The public body may, in its sole discretion, reject all proposals. Design-build contracts shall be awarded using the procedures in (a) or (b) of this subsection.
     (a) Best and final proposals shall be evaluated and scored based on the factors, weighting, and process identified in the initial request for proposals. The public body may score the proposals using a system that measures the quality and technical merits of the proposal on a unit price basis. Final proposals may not be considered if the proposal cost is greater than the maximum allowable construction cost identified in the initial request for proposals. The public body shall initiate negotiations with the firm submitting the highest scored best and final proposal. If the public body is unable to execute a contract with the firm submitting the highest scored best and final proposal, negotiations with that firm may be suspended or terminated and the public body may proceed to negotiate with the next highest scored firm. Public bodies shall continue in accordance with this procedure until a contract agreement is reached or the selection process is terminated.
     (b) If the public body determines that all finalists are capable of producing plans and specifications that adequately meet project requirements, the public body may award the contract to the firm that submits the responsive best and final proposal with the lowest price.
     (6) The firm awarded the contract shall provide a performance and payment bond for the contracted amount. The public body shall provide appropriate honorarium payments to finalists submitting best and final proposals who are not awarded a design-build contract. Honorarium payments shall be sufficient to generate meaningful competition among potential proposers on design-build projects.
     (7) The authority provided to the state ferry system in this section is limited to projects concerning construction, renovation, preservation, demolition, and reconstruction of ferry terminals and associated land-based facilities)) and is not subject to approval by the committee.
     (4) Except for utility projects, the design-build procedure may not be used to procure operations and maintenance services for a period longer than three years. State agency projects that propose to use the design-build-operate-maintain procedure shall submit cost estimates for the construction portion of the project consistent with the office of financial management's capital budget requirements. Operations and maintenance costs must be shown separately and must not be included as part of the capital budget request.

Sec. 202   RCW 39.10.080 and 1994 c 132 s 8 are each amended to read as follows:
     Notwithstanding the provisions of RCW 39.04.015, a public body using the design-build contracting procedure is authorized to negotiate an adjustment to the lowest bid or proposal price for a public works project ((awarded under RCW 39.10.050 and 39.10.060)) based upon agreed changes to the contract plans and specifications under the following conditions:
     (1) All responsive bids or proposal prices exceed the available funds, as certified by an appropriate fiscal officer;
     (2) The apparent low-responsive bid or proposal does not exceed the available funds by the greater of one hundred twenty-five thousand dollars or two percent for projects valued over ten million dollars; and
     (3) The negotiated adjustment will bring the bid or proposal price within the amount of available funds.

Sec. 203   RCW 39.10.070 and 1994 c 132 s 7 are each amended to read as follows:
     (1) A public body utilizing the ((alternative public works)) design-build contracting procedure((s authorized under RCW 39.10.050 and 39.10.060)) shall provide for:
     (a) ((The preparation of appropriate, complete, and coordinated design documents consistent with the procedure utilized;
     (b) To the extent appropriate, an independent review of the contract documents through value engineering or constructability studies prior to bid or proposal solicitation;
     (c))) Reasonable budget contingencies totaling not less than five percent of the anticipated contract value;
     (((d) To the extent appropriate, on-site architectural or engineering representatives during major construction or installation phases;
     (e))) (b) Employment of staff or consultants with expertise and prior experience in the management of comparable projects; ((and
     (f))) (c) Contract documents that include alternative dispute resolution procedures to be attempted prior to the initiation of litigation;
     (d) Submission of project information, as required by the board; and
     (e) Contract documents that require the contractor, subcontractors, and designers to submit project information required by the board.
     (2) A public body utilizing the ((alternative public works)) design-build contracting procedure((s under RCW 39.10.050 and 39.10.060)) may provide incentive payments to contractors for early completion, cost savings, or other goals if such payments are identified in the request for proposals.

NEW SECTION.  Sec. 204   DESIGN-BUILD CONTRACT AWARD. (1) Contracts for design-build services shall be awarded through a competitive process using public solicitation of proposals for design-build services. The public body shall publish at least once in a legal newspaper of general circulation published in, or as near as possible to, that part of the county in which the public work will be done, a notice of its request for qualifications from proposers for design-build services, and the availability and location of the request for proposal documents. The request for qualifications documents shall include:
     (a) A general description of the project that provides sufficient information for proposers to submit qualifications;
     (b) The reasons for using the design-build procedure;
     (c) A description of the qualifications to be required of the proposer including, but not limited to, submission of the proposer's accident prevention program;
     (d) A description of the process the public body will use to evaluate qualifications and finalists' proposals, including evaluation factors and the relative weight of factors and any specific forms to be used by the proposers;
     (i) Evaluation factors for request for qualifications shall include, but not be limited to, technical qualifications, such as specialized experience and technical competence; capability to perform; past performance of the proposers' team, including the architect-engineer and construction members; and other appropriate factors. Cost or price-related factors are not permitted in the request for qualifications phase;
     (ii) Evaluation factors for finalists' proposals shall include, but not be limited to, the factors listed in (d)(i) of this subsection, as well as technical approach design concept; proposal price; ability of professional personnel; past performance on similar projects; ability to meet time and budget requirements; ability to provide a performance and payment bond for the project; recent, current, and projected work loads of the firm; and location. Alternatively, if the public body determines that all finalists will be capable of producing a design that adequately meets project requirements, the public body may award the contract to the firm that submits the responsive proposal with the lowest price;
     (e) The form of the contract to be awarded;
     (f) The amount to be paid to finalists submitting responsive proposals and who are not awarded a design-build contract;
     (g) The schedule for the procurement process and the project; and
     (h) Other information relevant to the project.
     (2) The public body shall establish an evaluation committee to evaluate the responses to the request for qualifications based on the factors, weighting, and process identified in the request for qualifications. Based on the evaluation committee's findings, the public body shall select not more than five responsive and responsible finalists to submit proposals. The public body may, in its sole discretion, reject all proposals and shall provide its reasons for rejection in writing to all proposers.
     (3) Upon selection of the finalists, the public body shall issue a request for proposals to the finalists, which shall provide the following information:
     (a) A detailed description of the project including programmatic, performance, and technical requirements and specifications; functional and operational elements; minimum and maximum net and gross areas of any building; and, at the discretion of the public body, preliminary engineering and architectural drawings; and
     (b) The target budget for the design-build portion of the project.
     (4) The public body shall establish an evaluation committee to evaluate the proposals submitted by the finalists. Design-build contracts shall be awarded using the procedures in (a) or (b) of this subsection. The public body must identify in the request for qualifications which procedure will be used.
     (a) The finalists' proposals shall be evaluated and scored based on the factors, weighting, and process identified in the initial request for qualifications and in any addenda published by the public body. Public bodies may request best and final proposals from finalists. The public body shall initiate negotiations with the firm submitting the highest scored proposal. If the public body is unable to execute a contract with the firm submitting the highest scored proposal, negotiations with that firm may be suspended or terminated and the public body may proceed to negotiate with the next highest scored firm. Public bodies shall continue in accordance with this procedure until a contract agreement is reached or the selection process is terminated.
     (b) If the public body determines that all finalists are capable of producing a design that adequately meets project requirements, the public body may award the contract to the firm that submits the responsive proposal with the lowest price.
     (5) The firm awarded the contract shall provide a performance and payment bond for the contracted amount. The public body shall provide appropriate honorarium payments to finalists submitting best and final proposals that are not awarded a design-build contract. Honorarium payments shall be sufficient to generate meaningful competition among potential proposers on design-build projects. In determining the amount of the honorarium, the public body shall consider the level of effort required to meet the selection criteria.

Sec. 301   RCW 39.10.061 and 2003 c 352 s 3 and 2003 c 300 s 5 are each reenacted and amended to read as follows:
     (((1) Notwithstanding any other provision of law, and after complying with RCW 39.10.030, a public body may utilize the general contractor/construction manager procedure of public works contracting for public works projects authorized under subsection (2) of this section. For the purposes of this section, "general contractor/construction manager" means a firm with which a public body has selected and negotiated a maximum allowable construction cost to be guaranteed by the firm, after competitive selection through formal advertisement and competitive bids, to provide services during the design phase that may include life-cycle cost design considerations, value engineering, scheduling, cost estimating, constructability, alternative construction options for cost savings, and sequencing of work, and to act as the construction manager and general contractor during the construction phase.
     (2) Except those school districts proposing projects that are considered and approved by the school district project review board and those public hospital districts proposing projects that are considered and approved by the public hospital district project review board)) Subject to the process in section 107 or 108 of this act, public bodies ((authorized under this section)) may utilize the general contractor/construction manager procedure for public works projects ((valued over ten million dollars)) where:
     (((a))) (1) Implementation of the project involves complex scheduling ((requirements)), phasing, or coordination; ((or
     (b))) (2) The project involves construction at an ((existing)) occupied facility which must continue to operate during construction; ((or
     (c))) (3) The involvement of the general contractor/construction manager during the design stage is critical to the success of the project((.
     (3) Public bodies should select general contractor/construction managers early in the life of public works projects, and in most situations no later than the completion of schematic design.
     (4) Contracts for the services of a general contractor/construction manager under this section shall be awarded through a competitive process requiring the public solicitation of proposals for general contractor/construction manager services. The public solicitation of proposals shall include: A description of the project, including programmatic, performance, and technical requirements and specifications when available; the reasons for using the general contractor/construction manager procedure; a description of the qualifications to be required of the proposer, including submission of the proposer's accident prevention program; a description of the process the public body will use to evaluate qualifications and proposals, including evaluation factors and the relative weight of factors; the form of the contract to be awarded; the estimated maximum allowable construction cost; and the bid instructions to be used by the general contractor/construction manager finalists. Evaluation factors shall include, but not be limited to: Ability of professional personnel, past performance in negotiated and complex projects, and ability to meet time and budget requirements; the scope of work the general contractor/construction manager proposes to self-perform and its ability to perform it; location; recent, current, and projected work loads of the firm; and the concept of their proposal. A public body shall establish a committee to evaluate the proposals. After the committee has selected the most qualified finalists, these finalists shall submit final proposals, including sealed bids for the percent fee, which is the percentage amount to be earned by the general contractor/construction manager as overhead and profit, on the estimated maximum allowable construction cost and the fixed amount for the detailed specified general conditions work. The public body shall select the firm submitting the highest scored final proposal using the evaluation factors and the relative weight of factors published in the public solicitation of proposals.
     (5) The maximum allowable construction cost may be negotiated between the public body and the selected firm after the scope of the project is adequately determined to establish a guaranteed contract cost for which the general contractor/construction manager will provide a performance and payment bond. The guaranteed contract cost includes the fixed amount for the detailed specified general conditions work, the negotiated maximum allowable construction cost, the percent fee on the negotiated maximum allowable construction cost, and sales tax. If the public body is unable to negotiate a satisfactory maximum allowable construction cost with the firm selected that the public body determines to be fair, reasonable, and within the available funds, negotiations with that firm shall be formally terminated and the public body shall negotiate with the next highest scored firm and continue until an agreement is reached or the process is terminated. If the maximum allowable construction cost varies more than fifteen percent from the bid estimated maximum allowable construction cost due to requested and approved changes in the scope by the public body, the percent fee shall be renegotiated.
     (6) All subcontract work shall be competitively bid with public bid openings. When critical to the successful completion of a subcontractor bid package and after publication of notice of intent to determine bidder eligibility in a legal newspaper of general circulation published in or as near as possible to that part of the county in which the public work will be done at least twenty days before requesting qualifications from interested subcontract bidders, the owner and general contractor/construction manager may determine subcontractor bidding eligibility using the following evaluation criteria:
     (a) Adequate financial resources or the ability to secure such resources;
     (b) History of successful completion of a contract of similar type and scope;
     (c) Project management and project supervision personnel with experience on similar projects and the availability of such personnel for the project;
     (d) Current and projected workload and the impact the project will have on the subcontractor's current and projected workload;
     (e) Ability to accurately estimate the subcontract bid package scope of work;
     (f) Ability to meet subcontract bid package shop drawing and other coordination procedures;
     (g) Eligibility to receive an award under applicable laws and regulations; and
     (h) Ability to meet subcontract bid package scheduling requirements.
     The owner and general contractor/construction manager shall weigh the evaluation criteria and determine a minimum acceptable score to be considered an eligible subcontract bidder.
     After publication of notice of intent to determine bidder eligibility, subcontractors requesting eligibility shall be provided the evaluation criteria and weighting to be used by the owner and general contractor/construction manager to determine eligible subcontract bidders. After the owner and general contractor/construction manager determine eligible subcontract bidders, subcontractors requesting eligibility shall be provided the results and scoring of the subcontract bidder eligibility determination.
     Subcontract bid packages shall be awarded to the responsible bidder submitting the low responsive bid. The requirements of RCW 39.30.060 apply to each subcontract bid package. All subcontractors who bid work over three hundred thousand dollars shall post a bid bond and all subcontractors who are awarded a contract over three hundred thousand dollars shall provide a performance and payment bond for their contract amount. All other subcontractors shall provide a performance and payment bond if required by the general contractor/construction manager. If a general contractor/construction manager receives a written protest from a subcontractor bidder, the general contractor/construction manager shall not execute a contract for the subcontract bid package with anyone other than the protesting bidder without first providing at least two full business days' written notice of the general contractor/construction manager's intent to execute a contract for the subcontract bid package; provided that the protesting bidder submits notice in writing of its protest no later than two full business days following bid opening. Intermediate Saturdays, Sundays, and legal holidays are not counted. A low bidder who claims error and fails to enter into a contract is prohibited from bidding on the same project if a second or subsequent call for bids is made for the project. Except as provided for under subsection (7) of this section, bidding on subcontract work by the general contractor/construction manager or its subsidiaries is prohibited. The general contractor/construction manager may negotiate with the low-responsive bidder in accordance with RCW 39.10.080 or, if unsuccessful in such negotiations, rebid.
     (7) The general contractor/construction manager, or its subsidiaries, may bid on subcontract work if:
     (a) The work within the subcontract bid package is customarily performed by the general contractor/construction manager;
     (b) The bid opening is managed by the public body; and
     (c) Notification of the general contractor/construction manager's intention to bid is included in the public solicitation of bids for the bid package.
     In no event may the value of subcontract work performed by the general contractor/construction manager exceed thirty percent of the negotiated maximum allowable construction cost.
     (8) A public body may include an incentive clause in any contract awarded under this section for savings of either time or cost or both from that originally negotiated. No incentives granted may exceed five percent of the maximum allowable construction cost. If the project is completed for less than the agreed upon maximum allowable construction cost, any savings not otherwise negotiated as part of an incentive clause shall accrue to the public body. If the project is completed for more than the agreed upon maximum allowable construction cost, excepting increases due to any contract change orders approved by the public body, the additional cost shall be the responsibility of the general contractor/construction manager.
     (9) The authority provided to the state ferry system in this section is limited to projects concerning construction, renovation, preservation, demolition, and reconstruction of ferry terminals and associated land-based facilities));
     (4) The project encompasses a complex or technical work environment; or
     (5) The project requires specialized work on a building that has historic significance.

NEW SECTION.  Sec. 302   PROJECT MANAGEMENT AND CONTRACTING REQUIREMENTS. (1) A public body using the general contractor/construction manager contracting procedure shall provide for:
     (a) The preparation of appropriate, complete, and coordinated design documents;
     (b) Confirmation that a constructability analysis of the design documents has been performed prior to solicitation of a subcontract bid package;
     (c) Reasonable budget contingencies totaling not less than five percent of the anticipated contract value;
     (d) To the extent appropriate, on-site architectural or engineering representatives during major construction or installation phases;
     (e) Employment of staff or consultants with expertise and prior experience in the management of comparable projects, critical path method schedule review and analysis, and the administration, pricing, and negotiation of change orders;
     (f) Contract documents that include alternative dispute resolution procedures to be attempted before the initiation of litigation;
     (g) Contract documents that: (i) Obligate the public owner to accept or reject a request for equitable adjustment, change order, or claim within a specified time period but no later than sixty calendar days after the receipt by the public body of related documentation; and (ii) provide that if the public owner does not respond in writing to a request for equitable adjustment, change order, or claim within the specified time period, the request is deemed denied;
     (h) Submission of project information, as required by the board; and
     (i) Contract documents that require the contractor, subcontractors, and designers to submit project information required by the board.
     (2) A public body using the general contractor/construction manager contracting procedure may include an incentive clause for early completion, cost savings, or other performance goals if such incentives are identified in the request for proposals. No incentives granted may exceed five percent of the maximum allowable construction cost. No incentives may be paid from any contingency fund established for coordination of the construction documents or coordination of the work.
     (3) If the construction is completed for less than the maximum allowable construction cost, any savings not otherwise negotiated as part of an incentive clause shall accrue to the public body. If the construction is completed for more than the maximum allowable construction cost, the additional cost is the responsibility of the general contractor/construction manager.
     (4) If the public body and the general contractor/construction manager agree, in writing, on a price for additional work, the public body must issue a change order within thirty days of the written agreement. If the public body does not issue a change order within the thirty days, interest shall accrue on the dollar amount of the additional work satisfactorily completed until a change order is issued. The public body shall pay this interest at a rate of one percent per month.

NEW SECTION.  Sec. 303   CONTRACT AWARD. (1) Public bodies should select general contractor/construction managers early in the life of public works projects, and in most situations no later than the completion of schematic design.
     (2) Contracts for the services of a general contractor/ construction manager under this section shall be awarded through a competitive process requiring the public solicitation of proposals for general contractor/construction manager services. The public solicitation of proposals shall include:
     (a) A description of the project, including programmatic, performance, and technical requirements and specifications when available;
     (b) The reasons for using the general contractor/construction manager procedure;
     (c) A description of the qualifications to be required of the firm, including submission of the firm's accident prevention program;
     (d) A description of the process the public body will use to evaluate qualifications and proposals, including evaluation factors and the relative weight of factors;
     (e) The form of the contract, including any contract for preconstruction services, to be awarded;
     (f) The estimated maximum allowable construction cost; and
     (g) The bid instructions to be used by the general contractor/ construction manager finalists.
     (3) Evaluation factors for selection of the general contractor/construction shall include, but not be limited to:
     (a) Ability of the firm's professional personnel;
     (b) The firm's past performance in negotiated and complex projects;
     (c) The firm's ability to meet time and budget requirements;
     (d) The scope of work the firm proposes to self-perform and its ability to perform that work;
     (e) The firm's proximity to the project location;
     (f) Recent, current, and projected work loads of the firm; and
     (g) The firm's approach to executing the project.
     (4) A public body shall establish a committee to evaluate the proposals. After the committee has selected the most qualified finalists, these finalists shall submit final proposals, including sealed bids for the percent fee on the estimated maximum allowable construction cost and the fixed amount for the general conditions work specified in the request for proposal. The public body shall select the firm submitting the highest scored final proposal using the evaluation factors and the relative weight of factors published in the public solicitation of proposals. A public body shall not evaluate or disqualify a proposal based on the terms of a collective bargaining agreement.
     (5) Public bodies may contract with the selected firm to provide services during the design phase that may include life-cycle cost design considerations, value engineering, scheduling, cost estimating, constructability, alternative construction options for cost savings, and sequencing of work, and to act as the construction manager and general contractor during the construction phase.

NEW SECTION.  Sec. 304   MAXIMUM ALLOWABLE CONSTRUCTION COST. (1) The maximum allowable construction cost shall be used to establish a total contract cost for which the general contractor/construction manager shall provide a performance and payment bond. The maximum allowable construction cost shall be negotiated between the public body and the selected firm when the construction documents and specifications are at least ninety percent complete.
     (2) Major bid packages may be bid in accordance with section 305 of this act before agreement on the maximum allowable construction cost between the public body and the selected general contractor/construction manager. The general contractor/construction manager may issue an intent to award to the responsible bidder submitting the lowest responsive bid.
     (3) The public body may, at its option, authorize the general contractor/construction manager to proceed with the bidding and award of bid packages and construction before receipt of complete project plans and specifications. Any contracts awarded under this subsection shall be incorporated in the negotiated maximum allowable construction cost.
     (4) The total contract cost includes the fixed amount for the detailed specified general conditions work, the negotiated maximum allowable construction cost, the negotiated support services, and the percent fee on the negotiated maximum allowable construction cost. Negotiated support services may be included in the specified general conditions at the discretion of the public body.
     (5) If the public body is unable to negotiate a satisfactory maximum allowable construction cost with the firm selected that the public body determines to be fair, reasonable, and within the available funds, negotiations with that firm shall be formally terminated and the public body shall negotiate with the next highest scored firm and continue until an agreement is reached or the process is terminated.
     (6) If the maximum allowable construction cost varies more than fifteen percent from the bid estimated maximum allowable construction cost due to requested and approved changes in the scope by the public body, the percent fee shall be renegotiated.

NEW SECTION.  Sec. 305   SUBCONTRACT BIDDING PROCEDURE. (1) All subcontract work and equipment and material purchases shall be competitively bid with public bid openings. Subcontract bid packages and equipment and materials purchases shall be awarded to the responsible bidder submitting the lowest responsive bid. In preparing subcontract bid packages, the general contractor/construction manager shall not be required to violate or waive terms of a collective bargaining agreement.
     (2) All subcontract bid packages in which bidder eligibility was not determined in advance shall include the specific objective criteria that will be used by the general contractor/construction manager and the public body to evaluate bidder responsibility. If the lowest bidder submitting a responsive bid is determined by the general contractor/construction manager and the public body not to be responsible, the general contractor/construction manager and the public body must provide written documentation to that bidder explaining their intent to reject the bidder as not responsible and afford the bidder the opportunity to establish that it is a responsible bidder. Responsibility shall be determined in accordance with criteria listed in the bid documents. Protests concerning bidder responsibility determination by the general contractor/construction manager and the public body shall be in accordance with subsection (4) of this section.
     (3) All subcontractors who bid work over three hundred thousand dollars shall post a bid bond. All subcontractors who are awarded a contract over three hundred thousand dollars shall provide a performance and payment bond for the contract amount. All other subcontractors shall provide a performance and payment bond if required by the general contractor/construction manager.
     (4) If the general contractor/construction manager receives a written protest from a subcontractor bidder or an equipment or material supplier, the general contractor/construction manager shall not execute a contract for the subcontract bid package or equipment or material purchase order with anyone other than the protesting bidder without first providing at least two full business days' written notice to all bidders of the intent to execute a contract for the subcontract bid package. The protesting bidder must submit written notice of its protest no later than two full business days following the bid opening. Intermediate Saturdays, Sundays, and legal holidays are not counted.
     (5) A low bidder who claims error and fails to enter into a contract is prohibited from bidding on the same project if a second or subsequent call for bids is made for the project.
     (6) The general contractor/construction manager may negotiate with the lowest responsible and responsive bidder to negotiate an adjustment to the lowest bid or proposal price based upon agreed changes to the contract plans and specifications under the following conditions:
     (a) All responsive bids or proposal prices exceed the available funds, as certified by an appropriate fiscal officer;
     (b) The apparent low responsive bid or proposal does not exceed the available funds by the greater of one hundred twenty-five thousand dollars or two percent for projects valued over ten million dollars; and
     (c) The negotiated adjustment will bring the bid or proposal price within the amount of available funds.
     (7) If the negotiation is unsuccessful, the subcontract work or equipment or material purchases must be rebid.
     (8) The general contractor/construction manager must provide a written explanation if all bids are rejected.

NEW SECTION.  Sec. 306   GENERAL CONTRACTOR/CONSTRUCTION MANAGER SELF PERFORMANCE OF SUBCONTRACT WORK. (1) Except as provided in this section, bidding on subcontract work or for the supply of equipment or materials by the general contractor/construction manager or its subsidiaries is prohibited.
     (2) The general contractor/construction manager, or its subsidiaries, may bid on subcontract work or for the supply of equipment or materials if:
     (a) The work within the subcontract bid package or equipment or materials is customarily performed or supplied by the general contractor/construction manager;
     (b) The bid opening is managed by the public body and is in compliance with section 305 of this act; and
     (c) Notification of the general contractor/construction manager's intention to bid is included in the public solicitation of bids for the bid package or for the equipment or materials.
     (3) In no event may the general contractor/construction manager or its subsidiaries purchase equipment or materials for assignment to subcontract bid package bidders for installation or warranty. The value of subcontract work performed and equipment and materials supplied by the general contractor/construction manager may not exceed thirty percent of the negotiated maximum allowable construction cost. Negotiated support services performed by the general contractor/construction manager shall not be considered subcontract work for purposes of this subsection.

NEW SECTION.  Sec. 307   PREBID DETERMINATION OF SUBCONTRACTOR ELIGIBILITY. (1) If determination of subcontractor eligibility prior to seeking bids is in the best interest of the project and critical to the successful completion of a subcontract bid package, the general contractor/construction manager and the public body may determine subcontractor eligibility to bid. The general contractor/construction manager and the public body must:
     (a) Conduct a hearing and provide an opportunity for any interested party to submit written and verbal comments regarding the justification for conducting bidder eligibility, the evaluation criteria, and weights for each criteria and subcriteria;
     (b) Publish a notice of intent to evaluate and determine bidder eligibility in a legal newspaper published in or as near as possible to that part of the county where the public work will be constructed at least fourteen calendar days before conducting a public hearing;
     (c) Ensure the public hearing notice includes the date, time, and location of the hearing, a statement justifying the basis and need for performing eligibility analysis before bid opening, and specific eligibility criteria and applicable weights given to each criteria and subcriteria that will be used during evaluation;
     (d) After the public hearing, consider written and verbal comments received and determine if establishing bidder eligibility in advance of seeking bids is in the best interests of the project and critical to the successful completion of a subcontract bid package; and
     (e) Issue a written final determination to all interested parties. All protests of the decision to establish bidder eligibility before issuing a subcontractor bid package must be filed with the superior court within seven calendar days of the final determination. Any modifications to the eligibility criteria and weights shall be based on comments received during the public hearing process and shall be included in the final determination.
     (2) Determinations of bidder eligibility shall be in accordance with the evaluation criteria and weights for each criteria established in the final determination and shall be provided to interested persons upon request. Any potential bidder determined not to meet eligibility criteria must be afforded the opportunity to establish its eligibility. Protests concerning bidder eligibility determinations shall be in accordance with subsection (1) of this section.

NEW SECTION.  Sec. 308   SUBCONTRACT AGREEMENTS. Subcontract agreements used by the general contractor/construction manager shall not:
     (1) Delegate, restrict, or assign the general contractor/construction manager's implied duty not to hinder or delay the subcontractor. Nothing in this subsection (1) prohibits the general contractor/construction manager from requiring subcontractors not to hinder or delay the work of the general contractor/construction manager or other subcontractors and to hold subcontractors responsible for such damages;
     (2) Delegate, restrict, or assign the general contractor/construction manager's authority to resolve subcontractor conflicts. The general contractor/construction manager may delegate or assign coordination of specific elements of the work, including: (a) The coordination of shop drawings among subcontractors; (b) the coordination among subcontractors in ceiling spaces and mechanical rooms; and (c) the coordination of a subcontractor's lower tier subcontractors. Nothing in this subsection prohibits the general contractor/construction manager from imposing a duty on its subcontractors to cooperate with the general contractor/construction manager and other subcontractors in the coordination of the work;
     (3) Restrict the subcontractor's right to damages for changes to the construction schedule or work to the extent that the delay or disruption is caused by the general contractor/construction manager or entities acting for it. The general contractor/construction manager may require the subcontractor to provide notice that rescheduling or resequencing will result in delays or additional costs;
     (4) Require the subcontractor to bear the cost of trade damage repair except to the extent the subcontractor is responsible for the damage. Nothing in this subsection (4) precludes the general contractor/construction manager from requiring the subcontractor to take reasonable steps to protect the subcontractor's work from trade damage; or
     (5) Require the subcontractor to execute progress payment applications that waive claims for additional time or compensation or bond or retainage rights as a condition of receipt of progress payment, except to the extent the subcontractor has received or will receive payment. Nothing in this section precludes the general contractor/construction manager from requiring the subcontractor to provide notice of claims for additional time or compensation as a condition precedent to right of recovery or to execute a full and final release, including a waiver of bond and retainage rights, as a condition of final payment.

Sec. 401   RCW 39.10.130 and 2003 c 301 s 1 are each amended to read as follows:
     (1) The following public bodies are authorized to use the job order contracting procedure:
     (a) The department of general administration;
     (b) The University of Washington;
     (c) Washington State University;
     (d) Every city with a population greater than seventy thousand and any public authority chartered by such city under RCW 35.21.730 through 35.21.755;
     (e) Every county with a population greater than four hundred fifty thousand;
     (f) Every port district with total revenues greater than fifteen million dollars per year;
     (g) Every public utility district with revenues from energy sales greater than twenty-three million dollars per year;
     (h) Every school district; and
     (i) The state ferry system.
     (2) The department of general administration may issue job order contract work orders for Washington state parks department projects.
     (3) Public bodies may use a job order contract for public works projects when((:
     (a) A public body has made)) a determination is made that the use of job order contracts will benefit the public by providing an effective means of reducing the total lead-time and cost for the construction of public works projects ((or)) for repair and renovation required at public facilities through the use of unit price books and work orders by eliminating time-consuming, costly aspects of the traditional public works process, which require separate contracting actions for each small project((;
     (b) The work order to be issued for a particular project does not exceed two hundred thousand dollars;
     (c) Less than twenty percent of the dollar value of the work order consists of items of work not contained in the unit price book; and
     (d) At least eighty percent of the job order contract must be subcontracted to entities other than the job order contractor.
     (2) Public bodies shall award job order contracts through a competitive process utilizing public requests for proposals. Public bodies shall make an effort to solicit proposals from a certified minority or certified woman-owned contractor to the extent permitted by the Washington state civil rights act, RCW 49.60.400. The public body shall publish, at least once in a legal newspaper of general circulation published in or as near as possible to that part of the county in which the public works will be done, a request for proposals for job order contracts and the availability and location of the request for proposal documents. The public body shall ensure that the request for proposal documents at a minimum includes:
     (a) A detailed description of the scope of the job order contract including performance, technical requirements and specifications, functional and operational elements, minimum and maximum work order amounts, duration of the contract, and options to extend the job order contract;
     (b) The reasons for using job order contracts;
     (c) A description of the qualifications required of the proposer;
     (d) The identity of the specific unit price book to be used;
     (e) The minimum contracted amount committed to the selected job order contractor;
     (f) A description of the process the public body will use to evaluate qualifications and proposals, including evaluation factors and the relative weight of factors. The public body shall ensure that evaluation factors include, but are not limited to, proposal price and the ability of the proposer to perform the job order contract. In evaluating the ability of the proposer to perform the job order contract, the public body may consider: The ability of the professional personnel who will work on the job order contract; past performance on similar contracts; ability to meet time and budget requirements; ability to provide a performance and payment bond for the job order contract; recent, current, and projected work loads of the proposer; location; and the concept of the proposal;
     (g) The form of the contract to be awarded;
     (h) The method for pricing renewals of or extensions to the job order contract;
     (i) A notice that the proposals are subject to the provisions of RCW 39.10.100; and
     (j) Other information relevant to the project.
     (3) A public body shall establish a committee to evaluate the proposals. After the committee has selected the most qualified finalists, the finalists shall submit final proposals, including sealed bids based upon the identified unit price book. Such bids may be in the form of coefficient markups from listed price book costs. The public body shall award the contract to the firm submitting the highest scored final proposal using the evaluation factors and the relative weight of factors published in the public request for proposals.
     (4) The public body shall provide a protest period of at least ten business days following the day of the announcement of the apparent successful proposal to allow a protester to file a detailed statement of the grounds of the protest. The public body shall promptly make a determination on the merits of the protest and provide to all proposers a written decision of denial or acceptance of the protest. The public body shall not execute the contract until two business days following the public body's decision on the protest.
     (5) The public body shall issue no work orders until it has approved, in consultation with the office of minority and women's business enterprises or the equivalent local agency, a plan prepared by the job order contractor that equitably spreads certified women and minority business enterprise subcontracting opportunities, to the extent permitted by the Washington state civil rights act, RCW 49.60.400, among the various subcontract disciplines.
     (6) Job order contracts may be executed for an initial contract term of not to exceed two years, with the option of extending or renewing the job order contract for one year. All extensions or renewals must be priced as provided in the request for proposals. The extension or renewal must be mutually agreed to by the public body and the job order contractor.
     (7) The maximum total dollar amount that may be awarded under a job order contract shall not exceed three million dollars in the first year of the job order contract, five million dollars over the first two years of the job order contract, and, if extended or renewed, eight million dollars over the three years of the job order contract.
     (8) For each job order contract, public bodies shall not issue more than two work orders equal to or greater than one hundred fifty thousand dollars in a twelve-month contract performance period.
     (9) All work orders issued for the same project shall be treated as a single work order for purposes of the one hundred fifty thousand dollar limit on work orders in subsection (8) of this section and the two hundred thousand dollar limit on work orders in subsection (1)(b) of this section.
     (10) Any new permanent, enclosed building space constructed under a work order shall not exceed two thousand gross square feet.
     (11) Each public body may have no more than two job order contracts in effect at any one time.
     (12) For purposes of chapters 39.08, 39.12, 39.76, and 60.28 RCW, each work order issued shall be treated as a separate contract. The alternate filing provisions of RCW 39.12.040(2) shall apply to each work order that otherwise meets the eligibility requirements of RCW 39.12.040(2).
     (13) The requirements of RCW 39.30.060 do not apply to requests for proposals for job order contracts.
     (14) Job order contractors shall pay prevailing wages for all work that would otherwise be subject to the requirements of chapter 39.12 RCW. Prevailing wages for all work performed pursuant to each work order must be the rates in effect at the time the individual work order is issued.
     (15) If, in the initial contract term, the public body, at no fault of the job order contractor, fails to issue the minimum amount of work orders stated in the public request for proposals, the public body shall pay the contractor an amount equal to the difference between the minimum work order amount and the actual total of the work orders issued multiplied by an appropriate percentage for overhead and profit contained in the general conditions for Washington state facility construction. This will be the contractor's sole remedy.
     (16) All job order contracts awarded under this section must be executed before July 1, 2007, however the job order contract may be extended or renewed as provided for in this section.
     (17) For purposes of this section, "public body" includes any school district)).

NEW SECTION.  Sec. 402   CONTRACT AWARD. (1) Job order contracts shall be awarded through a competitive process using public requests for proposals.
     (2) The public body shall make an effort to solicit proposals from certified minority or certified woman-owned contractors to the extent permitted by the Washington state civil rights act, RCW 49.60.400.
     (3) The public body shall publish, at least once in a statewide publication and legal newspaper of general circulation published in every county in which the public works project is anticipated, a request for proposals for job order contracts and the availability and location of the request for proposal documents. The public body shall ensure that the request for proposal documents at a minimum includes:
     (a) A detailed description of the scope of the job order contract including performance, technical requirements and specifications, functional and operational elements, minimum and maximum work order amounts, duration of the contract, and options to extend the job order contract;
     (b) The reasons for using job order contracts;
     (c) A description of the qualifications required of the proposer;
     (d) The identity of the specific unit price book to be used;
     (e) The minimum contracted amount committed to the selected job order contractor;
     (f) A description of the process the public body will use to evaluate qualifications and proposals, including evaluation factors and the relative weight of factors. The public body shall ensure that evaluation factors include, but are not limited to, proposal price and the ability of the proposer to perform the job order contract. In evaluating the ability of the proposer to perform the job order contract, the public body may consider: The ability of the professional personnel who will work on the job order contract; past performance on similar contracts; ability to meet time and budget requirements; ability to provide a performance and payment bond for the job order contract; recent, current, and projected work loads of the proposer; location; and the concept of the proposal;
     (g) The form of the contract to be awarded;
     (h) The method for pricing renewals of or extensions to the job order contract;
     (i) A notice that the proposals are subject to RCW 39.10.100 (as recodified by this act); and
     (j) Other information relevant to the project.
     (4) A public body shall establish a committee to evaluate the proposals. After the committee has selected the most qualified finalists, the finalists shall submit final proposals, including sealed bids based upon the identified unit price book. Such bids may be in the form of coefficient markups from listed price book costs. The public body shall award the contract to the firm submitting the highest scored final proposal using the evaluation factors and the relative weight of factors published in the public request for proposals and will notify the board of the award of the contract.
     (5) The public body shall provide a protest period of at least ten business days following the day of the announcement of the apparent successful proposal to allow a protester to file a detailed statement of the grounds of the protest. The public body shall promptly make a determination on the merits of the protest and provide to all proposers a written decision of denial or acceptance of the protest. The public body shall not execute the contract until two business days following the public body's decision on the protest.
     (6) The requirements of RCW 39.30.060 do not apply to requests for proposals for job order contracts.

NEW SECTION.  Sec. 403   JOB ORDER CONTRACT REQUIREMENTS. (1) The maximum total dollar amount that may be awarded under a job order contract is four million dollars per year for a maximum of three years.
     (2) Job order contracts may be executed for an initial contract term of not to exceed two years, with the option of extending or renewing the job order contract for one year. All extensions or renewals must be priced as provided in the request for proposals. The extension or renewal must be mutually agreed to by the public body and the job order contractor.
     (3) A public body may have no more than two job order contracts in effect at any one time, with the exception of the department of general administration, which may have four job order contracts in effect at any one time.
     (4) At least ninety percent of work contained in a job order contract must be subcontracted to entities other than the job order contractor. The job order contractor must distribute contracts as equitably as possible among qualified and available subcontractors including minority and woman-owned subcontractors to the extent permitted by law.
     (5) The job order contractor shall publish notification of intent to perform public works projects at the beginning of each contract year in a statewide publication and in a legal newspaper of general circulation in every county in which the public works projects are anticipated.
     (6) Job order contractors shall pay prevailing wages for all work that would otherwise be subject to the requirements of chapter 39.12 RCW. Prevailing wages for all work performed pursuant to each work order must be the rates in effect at the time the individual work order is issued.
     (7) If, in the initial contract term, the public body, at no fault of the job order contractor, fails to issue the minimum amount of work orders stated in the public request for proposals, the public body shall pay the contractor an amount equal to the difference between the minimum work order amount and the actual total of the work orders issued multiplied by an appropriate percentage for overhead and profit contained in the contract award coefficient for services as specified in the request for proposals. This is the contractor's sole remedy.
     (8) All job order contracts awarded under this section must be signed before July 1, 2013; however the job order contract may be extended or renewed as provided for in this section.
     (9) Public bodies may amend job order contracts awarded prior to July 1, 2007, in accordance with this chapter.

NEW SECTION.  Sec. 404   WORK ORDERS. (1) The maximum dollar amount for a work order is three hundred fifty thousand dollars. For each job order contract, public bodies shall not issue more than two work orders equal to or greater than three hundred thousand dollars in a twelve-month contract period.
     (2) All work orders issued for the same project shall be treated as a single work order for purposes of the dollar limit on work orders.
     (3) No more than twenty percent of the dollar value of a work order may consist of items of work not contained in the unit price book.
     (4) Any new permanent, enclosed building space constructed under a work order shall not exceed two thousand gross square feet.
     (5) A public body may issue no work orders under a job order contract until it has approved, in consultation with the office of minority and women's business enterprises or the equivalent local agency, a plan prepared by the job order contractor that equitably spreads certified women and minority business enterprise subcontracting opportunities, to the extent permitted by the Washington state civil rights act, RCW 49.60.400, among the various subcontract disciplines.
     (6) For purposes of chapters 39.08, 39.12, 39.76, and 60.28 RCW, each work order issued shall be treated as a separate contract. The alternate filing provisions of RCW 39.12.040(2) apply to each work order that otherwise meets the eligibility requirements of RCW 39.12.040(2).
     (7) The job order contract shall not be used for the procurement of architectural or engineering services not associated with specific work orders. Architectural and engineering services shall be procured in accordance with RCW 39.80.040.

NEW SECTION.  Sec. 405   A public body shall provide to the board the following information for each job order contract at the end of each contract year:
     (1) A list of work orders issued;
     (2) The cost of each work order;
     (3) A list of subcontractors hired under each work order;
     (4) If requested by the board, a copy of the intent to pay prevailing wage and the affidavit of wages paid for each work order subcontract; and
     (5) Any other information requested by the board.

Sec. 501   RCW 39.10.120 and 2001 c 328 s 5 are each amended to read as follows:
     (((1) Except as provided in subsections (2) and (3) of this section,)) The alternative public works contracting procedures authorized under this chapter are limited to public works contracts signed before July 1, ((2007)) 2013. Methods of public works contracting authorized ((by RCW 39.10.050 and 39.10.060 or 39.10.051 and 39.10.061)) under this chapter shall remain in full force and effect until completion of contracts signed before July 1, ((2007)) 2013.
     (((2) For the purposes of a baseball stadium as defined in RCW 82.14.0485, the design-build contracting procedures under RCW 39.10.050 shall remain in full force and effect until completion of contracts signed before December 31, 1997.
     (3) For the purposes of a stadium and exhibition center, as defined in RCW 36.102.010, the design-build contracting procedures under RCW 39.10.050 or 39.10.051 shall remain in full force and effect until completion of contracts signed before December 31, 2002.
     (4) A public authority chartered by a city that is a public body may utilize an alternative public works contracting procedure under this chapter only after receiving specific authorization on a project-by-project basis from the governing body of the city. For purposes of public authorities authorized to use alternative public works contracting procedures under this chapter, the city chartering any such public authority shall itself comply with RCW 39.10.030 on behalf of the public authority.))

NEW SECTION.  Sec. 502   Projects approved by the school district project review board established under RCW 39.10.115, and the hospital district project review board established under RCW 39.10.117 before July 1, 2007, may proceed without the approval of the committee established in section 104 of this act. The board may grant an exemption from any provision of this act for projects advertised before the effective date of this section. A public body seeking an exemption must submit a request in writing to the board no later than December 31, 2007. The board must respond to the request within sixty calendar days.

NEW SECTION.  Sec. 503   Projects using the design-build or general contractor/construction manager contracting procedures in which advertising for selection of a contractor has begun by the effective date of this section but no contract has been awarded may proceed without seeking approval of the committee under the processes in sections 107 and 108 of this act.

Sec. 504   RCW 60.28.011 and 2003 c 301 s 7 are each amended to read as follows:
     (1) Public improvement contracts shall provide, and public bodies shall reserve, a contract retainage not to exceed five percent of the moneys earned by the contractor as a trust fund for the protection and payment of: (a) The claims of any person arising under the contract; and (b) the state with respect to taxes imposed pursuant to Title 82 RCW which may be due from such contractor.
     (2) Every person performing labor or furnishing supplies toward the completion of a public improvement contract shall have a lien upon moneys reserved by a public body under the provisions of a public improvement contract. However, the notice of the lien of the claimant shall be given within forty-five days of completion of the contract work, and in the manner provided in RCW 39.08.030.
     (3) The contractor at any time may request the contract retainage be reduced to one hundred percent of the value of the work remaining on the project.
     (a) After completion of all contract work other than landscaping, the contractor may request that the public body release and pay in full the amounts retained during the performance of the contract, and sixty days thereafter the public body must release and pay in full the amounts retained (other than continuing retention of five percent of the moneys earned for landscaping) subject to the provisions of chapters 39.12 and 60.28 RCW.
     (b) Sixty days after completion of all contract work the public body must release and pay in full the amounts retained during the performance of the contract subject to the provisions of chapters 39.12 and 60.28 RCW.
     (4) The moneys reserved by a public body under the provisions of a public improvement contract, at the option of the contractor, shall be:
     (a) Retained in a fund by the public body;
     (b) Deposited by the public body in an interest bearing account in a bank, mutual savings bank, or savings and loan association. Interest on moneys reserved by a public body under the provision of a public improvement contract shall be paid to the contractor;
     (c) Placed in escrow with a bank or trust company by the public body. When the moneys reserved are placed in escrow, the public body shall issue a check representing the sum of the moneys reserved payable to the bank or trust company and the contractor jointly. This check shall be converted into bonds and securities chosen by the contractor and approved by the public body and the bonds and securities shall be held in escrow. Interest on the bonds and securities shall be paid to the contractor as the interest accrues.
     (5) The contractor or subcontractor may withhold payment of not more than five percent from the moneys earned by any subcontractor or sub-subcontractor or supplier contracted with by the contractor to provide labor, materials, or equipment to the public project. Whenever the contractor or subcontractor reserves funds earned by a subcontractor or sub-subcontractor or supplier, the contractor or subcontractor shall pay interest to the subcontractor or sub-subcontractor or supplier at a rate equal to that received by the contractor or subcontractor from reserved funds.
     (6) A contractor may submit a bond for all or any portion of the contract retainage in a form acceptable to the public body and from a bonding company meeting standards established by the public body. The public body shall accept a bond meeting these requirements unless the public body can demonstrate good cause for refusing to accept it. This bond and any proceeds therefrom are subject to all claims and liens and in the same manner and priority as set forth for retained percentages in this chapter. The public body shall release the bonded portion of the retained funds to the contractor within thirty days of accepting the bond from the contractor. Whenever a public body accepts a bond in lieu of retained funds from a contractor, the contractor shall accept like bonds from any subcontractors or suppliers from which the contractor has retained funds. The contractor shall then release the funds retained from the subcontractor or supplier to the subcontractor or supplier within thirty days of accepting the bond from the subcontractor or supplier.
     (7) If the public body administering a contract, after a substantial portion of the work has been completed, finds that an unreasonable delay will occur in the completion of the remaining portion of the contract for any reason not the result of a breach thereof, it may, if the contractor agrees, delete from the contract the remaining work and accept as final the improvement at the stage of completion then attained and make payment in proportion to the amount of the work accomplished and in this case any amounts retained and accumulated under this section shall be held for a period of sixty days following the completion. In the event that the work is terminated before final completion as provided in this section, the public body may thereafter enter into a new contract with the same contractor to perform the remaining work or improvement for an amount equal to or less than the cost of the remaining work as was provided for in the original contract without advertisement or bid. The provisions of this chapter are exclusive and shall supersede all provisions and regulations in conflict herewith.
     (8) Whenever the department of transportation has contracted for the construction of two or more ferry vessels, sixty days after completion of all contract work on each ferry vessel, the department must release and pay in full the amounts retained in connection with the construction of the vessel subject to the provisions of RCW 60.28.020 and chapter 39.12 RCW. However, the department of transportation may at its discretion condition the release of funds retained in connection with the completed ferry upon the contractor delivering a good and sufficient bond with two or more sureties, or with a surety company, in the amount of the retained funds to be released to the contractor, conditioned that no taxes shall be certified or claims filed for work on the ferry after a period of sixty days following completion of the ferry; and if taxes are certified or claims filed, recovery may be had on the bond by the department of revenue and the materialmen and laborers filing claims.
     (9) Except as provided in subsection (1) of this section, reservation by a public body for any purpose from the moneys earned by a contractor by fulfilling its responsibilities under public improvement contracts is prohibited.
     (10) Contracts on projects funded in whole or in part by farmers home administration and subject to farmers home administration regulations are not subject to subsections (1) through (9) of this section.
     (11) This subsection applies only to a public body that has contracted for the construction of a facility using the general contractor/construction manager procedure, as defined under RCW ((39.10.061)) 39.10.020 (as recodified by this act). If the work performed by a subcontractor on the project has been completed within the first half of the time provided in the general contractor/construction manager contract for completing the work, the public body may accept the completion of the subcontract. The public body must give public notice of this acceptance. After a forty-five day period for giving notice of liens, and compliance with the retainage release procedures in RCW 60.28.021, the public body may release that portion of the retained funds associated with the subcontract. Claims against the retained funds after the forty-five day period are not valid.
     (12) Unless the context clearly requires otherwise, the definitions in this subsection apply throughout this section.
     (a) "Contract retainage" means an amount reserved by a public body from the moneys earned by a person under a public improvement contract.
     (b) "Person" means a person or persons, mechanic, subcontractor, or materialperson who performs labor or provides materials for a public improvement contract, and any other person who supplies the person with provisions or supplies for the carrying on of a public improvement contract.
     (c) "Public body" means the state, or a county, city, town, district, board, or other public body.
     (d) "Public improvement contract" means a contract for public improvements or work, other than for professional services, or a work order as defined in RCW 39.10.020 (as recodified by this act).

Sec. 505   RCW 70.150.070 and 2005 c 469 s 2 are each amended to read as follows:
     RCW 70.150.030 through 70.150.060 shall be deemed to provide an additional method for the provision of services from and in connection with facilities and shall be regarded as supplemental and additional to powers conferred by other state laws and by federal laws. ((A public body that is also eligible to enter into agreements with service providers under the alternative public works contracting procedures in chapter 39.10 RCW may elect to use either RCW 39.10.051 and 39.10.061 or this chapter as its method of procurement for such services.))

NEW SECTION.  Sec. 506   A new section is added to chapter 43.131 RCW to read as follows:
     The alternative works contracting procedures under chapter 39.10 RCW shall be terminated June 30, 2013, as provided in section 507 of this act.

NEW SECTION.  Sec. 507   A new section is added to chapter 43.131 RCW to read as follows:
     The following acts or parts of acts, as now existing or hereafter amended, are each repealed, effective June 30, 2014:
     (1) RCW 39.10.010 (as recodified by this act) and section 1 of this act & 1994 c 132 s 1;
     (2) RCW 39.10.020 (as recodified by this act) and section 101 of this act & 2005 c 469 s 3;
     (3) RCW 39.10.800 (as recodified by this act) and section 102 of this act & 2005 c 377 s 1;
     (4) RCW 39.10.810 (as recodified by this act) and section 103 of this act & 2005 c 377 s 2;
     (5) RCW 39.10.--- and section 104 of this act;
     (6) RCW 39.10.--- and section 105 of this act;
     (7) RCW 39.10.--- and section 106 of this act;
     (8) RCW 39.10.--- and section 107 of this act;
     (9) RCW 39.10.--- and section 108 of this act;
     (10) RCW 39.10.--- and section 109 of this act;
     (11) RCW 39.10.051 (as recodified by this act) and section 201 of this act, 2003 c 352 s 2, 2003 c 300 s 4, 2002 c 46 s 1, & 2001 c 328 s 2;
     (12) RCW 39.10.080 (as recodified by this act) and section 202 of this act & 1994 c 132 s 8;
     (13) RCW 39.10.070 (as recodified by this act) and section 203 of this act & 1994 c 132 s 7;
     (14) RCW 39.10.--- and section 204 of this act;
     (15) RCW 39.10.061 (as recodified by this act) and section 301 of this act, 2003 c 352 s 3, 2003 c 300 s 5, 2002 c 46 s 2, & 2001 c 328 s 3;
     (16) RCW 39.10.--- and section 302 of this act;
     (17) RCW 39.10.--- and section 303 of this act;
     (18) RCW 39.10.--- and section 304 of this act;
     (19) RCW 39.10.--- and section 305 of this act;
     (20) RCW 39.10.--- and section 306 of this act;
     (21) RCW 39.10.--- and section 307 of this act;
     (22) RCW 39.10.--- and section 308 of this act;
     (23) RCW 39.10.130 (as recodified by this act) and section 401 of this act & 2003 c 301 s 1;
     (24) RCW 39.10.--- and section 402 of this act;
     (25) RCW 39.10.--- and section 403 of this act;
     (26) RCW 39.10.--- and section 404 of this act;
     (27) RCW 39.10.--- and section 405 of this act;
     (28) RCW 39.10.100 (as recodified by this act) and 2005 c 274 s 275 & 1994 c 132 s 10;
     (29) RCW 39.10.090 (as recodified by this act) and 1994 c 132 s 9;
     (30) RCW 39.10.120 (as recodified by this act) and section 501 of this act & 2001 c 328 s 5;
     (31) RCW 39.10.--- and section 502 of this act;
     (32) RCW 39.10.--- and section 503 of this act;
     (33) RCW 39.10.900 (as recodified by this act) and 1994 c 132 s 13;
     (34) RCW 39.10.901 (as recodified by this act) and 1994 c 132 s 14; and
     (35) RCW 39.10.--- and section 510 of this act.

NEW SECTION.  Sec. 508   RCW 39.10.902 (Repealer) and 2006 c 261 s 3 & 2005 c 469 s 5 are each repealed.

NEW SECTION.  Sec. 509   The following acts or parts of acts are each repealed:
     (1) RCW 39.10.030 (Public notification and review process) and 1997 c 376 s 2 & 1994 c 132 s 3;
     (2) RCW 39.10.040 (Baseball stadium project -- Alternative procedure may be used) and 1994 c 132 s 4;
     (3) RCW 39.10.063 (City demonstration projects -- Conditions--Contract deadline) and 2005 c 377 s 3;
     (4) RCW 39.10.065 (Demonstration projects--Contract deadline--Transfer of authority to other public body) and 1997 c 376 s 5;
     (5) RCW 39.10.067 (School district capital demonstration projects--Conditions) and 2006 c 261 s 1, 2003 c 301 s 3, 2002 c 46 s 3, & 2000 c 209 s 3;
     (6) RCW 39.10.068 (Public hospital district capital demonstration projects -- Conditions) and 2003 c 300 s 6;
     (7) RCW 39.10.115 (School district project review board--Established -- Procedures) and 2006 c 261 s 2, 2001 c 328 s 4, & 2000 c 209 s 4; and
     (8) RCW 39.10.117 (Public hospital district project review board--Established -- Procedures) and 2003 c 300 s 7.

NEW SECTION.  Sec. 510   PART HEADINGS AND CAPTIONS NOT LAW. Part headings and captions used in this act are not any part of the law.

NEW SECTION.  Sec. 511   The following sections are codified or recodified in chapter 39.10 RCW in the following order:
     RCW 39.10.010
     RCW 39.10.020
     RCW 39.10.800
     RCW 39.10.810
     Section 104 of this act
     Section 105 of this act
     Section 106 of this act
     Section 107 of this act
     Section 108 of this act
     Section 109 of this act
     RCW 39.10.051
     RCW 39.10.080
     RCW 39.10.070
     Section 204 of this act
     RCW 39.10.061
     Section 302 of this act
     Section 303 of this act
     Section 304 of this act
     Section 305 of this act
     Section 306 of this act
     Section 307 of this act
     Section 308 of this act
     RCW 39.10.130
     Section 402 of this act
     Section 403 of this act
     Section 404 of this act
     Section 405 of this act
     RCW 39.10.100
     RCW 39.10.090
     RCW 39.10.120
     Section 502 of this act
     Section 503 of this act
     RCW 39.10.900
     RCW 39.10.901
     Section 510 of this act

NEW SECTION.  Sec. 512   This act is necessary for the immediate preservation of the public peace, health, or safety, or support of the state government and its existing public institutions, and takes effect July 1, 2007, except for section 104 of this act, which takes effect immediately, and section 508 of this act, which takes effect June 30, 2007.

NEW SECTION.  Sec. 513   If any provision of this act or its application to any person or circumstance is held invalid, the remainder of the act or the application of the provision to other persons or circumstances is not affected.